þ | QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
o | TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
Delaware | 33-0927079 | |
(State or other jurisdiction of incorporation or organization) |
(I.R.S. Employer Identification No.) |
1
(in thousands, except per share amounts) | 2006 | 2005 | ||||||
REVENUES |
$ | 3,364,036 | $ | 3,418,525 | ||||
COSTS AND EXPENSES |
||||||||
Cost of revenues |
3,317,401 | 3,237,647 | ||||||
Corporate administrative and general expense |
32,647 | 25,112 | ||||||
Interest expense |
6,429 | 3,853 | ||||||
Interest income |
(6,292 | ) | (5,551 | ) | ||||
Total Costs and Expenses |
3,350,185 | 3,261,061 | ||||||
EARNINGS BEFORE TAXES |
13,851 | 157,464 | ||||||
INCOME TAX EXPENSE (CREDIT) |
(13,487 | ) | 26,275 | |||||
NET EARNINGS |
$ | 27,338 | $ | 131,189 | ||||
EARNINGS PER SHARE |
||||||||
BASIC |
$ | 0.32 | $ | 1.54 | ||||
DILUTED |
$ | 0.31 | $ | 1.51 | ||||
SHARES USED TO CALCULATE EARNINGS PER SHARE |
||||||||
BASIC |
86,363 | 85,158 | ||||||
DILUTED |
88,933 | 87,140 | ||||||
DIVIDENDS DECLARED PER SHARE |
$ | 0.20 | $ | 0.16 | ||||
2
(in thousands, except per share amounts) | 2006 | 2005 | ||||||
REVENUES |
$ | 10,445,342 | $ | 9,198,234 | ||||
COSTS AND EXPENSES |
||||||||
Cost of revenues |
10,052,770 | 8,866,941 | ||||||
Corporate administrative and general expense |
128,720 | 90,873 | ||||||
Interest expense |
17,510 | 12,945 | ||||||
Interest income |
(16,837 | ) | (16,155 | ) | ||||
Total Costs and Expenses |
10,182,163 | 8,954,604 | ||||||
EARNINGS BEFORE TAXES |
263,179 | 243,630 | ||||||
INCOME TAX EXPENSE |
80,435 | 81,480 | ||||||
NET EARNINGS |
$ | 182,744 | $ | 162,150 | ||||
EARNINGS PER SHARE |
||||||||
BASIC |
$ | 2.12 | $ | 1.92 | ||||
DILUTED |
$ | 2.05 | $ | 1.88 | ||||
SHARES USED TO CALCULATE EARNINGS PER SHARE |
||||||||
BASIC |
86,179 | 84,617 | ||||||
DILUTED |
89,153 | 86,095 | ||||||
DIVIDENDS DECLARED PER SHARE |
$ | 0.60 | $ | 0.48 | ||||
3
September 30, | December 31, | |||||||
(in thousands, except share amounts) | 2006 | 2005 * | ||||||
ASSETS |
||||||||
Current assets |
||||||||
Cash and cash equivalents |
$ | 895,047 | $ | 789,016 | ||||
Accounts and notes receivable |
750,538 | 850,203 | ||||||
Contract work in progress |
1,061,680 | 1,110,650 | ||||||
Deferred taxes |
243,209 | 151,215 | ||||||
Other current assets |
345,477 | 207,138 | ||||||
Total current assets |
3,295,951 | 3,108,222 | ||||||
Property, plant and equipment (net of
accumulated depreciation of $518,165 and
$466,055, respectively) |
654,129 | 581,538 | ||||||
Investments and goodwill |
218,125 | 193,021 | ||||||
Deferred taxes |
97,384 | 75,797 | ||||||
Pension assets |
230,636 | 238,494 | ||||||
Other |
386,582 | 377,373 | ||||||
$ | 4,882,807 | $ | 4,574,445 | |||||
LIABILITIES AND SHAREHOLDERS EQUITY |
||||||||
Current liabilities |
||||||||
Trade accounts payable |
$ | 802,339 | $ | 1,003,886 | ||||
Equity bridge loan |
18,295 | | ||||||
Non-recourse project finance debt |
22,361 | | ||||||
Convertible Senior Notes |
329,999 | 330,000 | ||||||
Advance billings on contracts |
483,744 | 475,498 | ||||||
Accrued salaries, wages and benefits |
379,318 | 344,315 | ||||||
Other accrued liabilities |
362,970 | 185,636 | ||||||
Total current liabilities |
2,399,026 | 2,339,335 | ||||||
Long-term debt due after one year |
17,681 | 34,465 | ||||||
Non-recourse project finance debt |
116,377 | 57,558 | ||||||
Noncurrent liabilities |
523,228 | 512,529 | ||||||
Contingencies and commitments |
||||||||
Shareholders equity |
||||||||
Capital stock |
||||||||
Preferred authorized 20,000,000
shares ($0.01 par value); none
issued |
| | ||||||
Common authorized 150,000,000
shares ($0.01 par value); issued and outstanding 88,042,664 and 87,088,202 shares, respectively |
880 | 871 | ||||||
Additional capital |
645,194 | 629,901 | ||||||
Unamortized executive stock plan expense |
| (39,777 | ) | |||||
Accumulated other comprehensive income |
19,733 | 9,103 | ||||||
Retained earnings |
1,160,688 | 1,030,460 | ||||||
Total shareholders equity |
1,826,495 | 1,630,558 | ||||||
$ | 4,882,807 | $ | 4,574,445 | |||||
* | Amounts at December 31, 2005 have been derived from audited financial statements. |
4
(in thousands) | 2006 | 2005 | ||||||
CASH FLOWS FROM OPERATING ACTIVITIES |
||||||||
Net earnings |
$ | 182,744 | $ | 162,150 | ||||
Adjustments to reconcile net earnings to cash provided
by operating activities: |
||||||||
Depreciation of fixed assets |
86,132 | 74,695 | ||||||
Amortization of intangibles |
1,515 | 1,615 | ||||||
Restricted stock and stock option amortization |
25,932 | 13,829 | ||||||
Minority interest |
(11,734 | ) | (1,145 | ) | ||||
Deferred compensation trust assets |
(11,025 | ) | (10,589 | ) | ||||
Deferred compensation obligation |
15,123 | 8,587 | ||||||
Taxes paid on vested restricted stock |
(14,393 | ) | (9,184 | ) | ||||
Deferred taxes |
(119,739 | ) | 896 | |||||
Stock option tax benefit |
| 11,047 | ||||||
Retirement plan accrual, net of contributions |
16,311 | (12,450 | ) | |||||
Unbilled fees receivable |
| (32,594 | ) | |||||
Changes in operating assets and liabilities |
26,762 | 462,045 | ||||||
Gain on sale of real estate |
| (14,618 | ) | |||||
Equity in earnings of investees |
(10,474 | ) | (13,655 | ) | ||||
Insurance proceeds |
9,345 | 5,715 | ||||||
Currency translation |
13,783 | 9,056 | ||||||
Other items |
(24,227 | ) | 4,115 | |||||
Cash provided by operating activities |
186,055 | 659,515 | ||||||
CASH FLOWS FROM INVESTING ACTIVITIES |
||||||||
Capital expenditures |
(187,556 | ) | (145,277 | ) | ||||
Investments, net |
(314 | ) | (13,604 | ) | ||||
Proceeds from sale of real estate |
| 45,049 | ||||||
Proceeds from disposal of property, plant and equipment |
28,285 | 17,020 | ||||||
Other items |
(1,852 | ) | (1,955 | ) | ||||
Cash utilized by investing activities |
(161,437 | ) | (98,767 | ) | ||||
CASH FLOWS FROM FINANCING ACTIVITIES |
||||||||
Decrease in short-term borrowings |
| (129,940 | ) | |||||
Net proceeds from issuance of common stock |
| 41,820 | ||||||
Proceeds from issuance of non-recourse project financing |
76,050 | | ||||||
Stock options and warrants exercised |
31,726 | 40,198 | ||||||
Stock option tax benefit |
12,260 | | ||||||
Cash dividends paid |
(35,254 | ) | (41,477 | ) | ||||
Other items |
(447 | ) | (1,293 | ) | ||||
Cash provided (utilized) by financing activities |
84,335 | (90,692 | ) | |||||
Effect of exchange rate changes on cash |
(2,922 | ) | (27,261 | ) | ||||
Increase in cash and cash equivalents |
106,031 | 442,795 | ||||||
Cash and cash equivalents at beginning of period |
789,016 | 604,517 | ||||||
Cash and cash equivalents at end of period |
$ | 895,047 | $ | 1,047,312 | ||||
5
(1) | The Condensed Consolidated Financial Statements as of September 30, 2006 and December 31, 2005 and for the three and nine month periods ended September 30, 2006 and 2005 do not include footnotes and certain financial information normally presented annually under accounting principles generally accepted in the United States, and therefore should be read in conjunction with the companys December 31, 2005 annual report on Form 10-K. Accounting measurements at interim dates inherently involve greater reliance on estimates than at year-end. The results of operations for the three and nine months ended September 30, 2006 are not necessarily indicative of results that can be expected for the full year. | |
The Condensed Consolidated Financial Statements included herein are unaudited; however, they contain all adjustments (consisting of normal recurring accruals, including certain contract loss provisions) which, in the opinion of the company, are necessary to present fairly its consolidated financial position at September 30, 2006 and its consolidated results of operations for the three and nine months ended September 30, 2006 and 2005 and its cash flows for the nine months ended September 30, 2006 and 2005. | ||
Certain 2005 amounts have been reclassified to conform with the 2006 presentation. | ||
(2) | The components of comprehensive income, net of related tax, are as follows: |
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in thousands | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Net earnings |
$ | 27,338 | $ | 131,189 | $ | 182,744 | $ | 162,150 | ||||||||
Foreign currency translation adjustment |
504 | 16,474 | 10,630 | (18,338 | ) | |||||||||||
Comprehensive income |
$ | 27,842 | $ | 147,663 | $ | 193,374 | $ | 143,812 | ||||||||
(3) | Due to the utilization of net operating loss and capital loss carryforwards and an increase in the extraterritorial income exclusion and the domestic production activities deduction, a tax credit of $13.5 million was recorded for the third quarter of 2006. These factors reduced the effective tax rate, based on the companys actual operating results for the nine months ended September 30, 2006, to 30.6 percent. The effective tax rates were 16.7 percent and 33.4 percent, respectively, for the three and nine month periods ended September 30, 2005. The set-aside of a jury verdict and no-liability resolution of a Cayman Islands hotel project, along with the settlement of the Hamaca Crude Upgrader project claims during the third quarter of 2005 substantially reversed the foreign losses recorded in prior quarters of 2005 and restored the companys ability to absorb foreign taxes incurred in high tax jurisdictions. These, coupled with the tax benefit attributable to the foreign repatriation provision enacted under the American Jobs Creation Act of 2004 gave rise to the low effective tax rate in the third quarter of 2005. | |
Judgment is required in determining the consolidated provision for income taxes as the company considers its worldwide taxable earnings and the impact of the continuous audit process conducted by various tax authorities. The final outcome of these audits by foreign jurisdictions, the Internal Revenue Service and various state governments could differ materially from that which is reflected in the Condensed Consolidated Financial Statements. | ||
In June 2006, the Financial Accounting Standards Board (FASB) issued FASB Interpretation No. 48, Accounting for Uncertainty in Income Taxes (FIN 48). This interpretation addresses the noncomparability in reporting tax assets and liabilities resulting from a lack of specific guidance in FASB Statement of Financial Accounting Standards (SFAS) No. 109, Accounting for Income Taxes (SFAS 109) on the uncertainty in income taxes recognized in financial |
6
statements. Specifically, FIN 48 prescribes a consistent recognition threshold and measurement attribute for the recognition and measurement of a tax position taken or expected to be taken in a tax return and provides guidance on derecognition, classification, interest and penalties, as well as interim period accounting and disclosure. The interpretation will apply to fiscal years beginning after December 15, 2006, with earlier adoption permitted. | ||
The company has not yet completed its assessment of the effects of applying the provisions of FIN 48. | ||
(4) | Cash paid for interest was $13.5 million and $14.3 million for the nine months ended September 30, 2006 and 2005, respectively. Income tax payments, net of receipts, were $129.5 million and $70.7 million during the nine-month periods ended September 30, 2006 and 2005, respectively. | |
(5) | The significant increase in the trading prices of the companys common stock over the past year has resulted in greater impacts of dilutive securities in earnings per share (EPS) computations for 2006 periods. Dilutive securities included in EPS computations are as follows: |
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
(shares in thousands) | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Employee stock options and restricted
stock |
733 | 1,023 | 715 | 989 | ||||||||||||
Conversion equivalent of dilutive
convertible debt |
1,607 | 773 | 2,003 | 314 | ||||||||||||
Warrant |
230 | 186 | 256 | 175 | ||||||||||||
Total |
2,570 | 1,982 | 2,974 | 1,478 | ||||||||||||
(6) | In December 2004, the FASB issued SFAS No. 123 (revised 2004), Share-Based Payment (SFAS 123-R), which is a revision of SFAS 123, Accounting for Stock-Based Compensation. SFAS 123-R supersedes Accounting Principles Board (APB) Opinion No. 25, Accounting for Stock Issued to Employees (APB 25), and amends SFAS 95, Statement of Cash Flows. Generally, the approach in SFAS 123-R is similar to the approach described in SFAS 123. However, SFAS 123-R requires all share-based payments to employees, including grants of employee stock options, to be recognized in the income statement based on their fair values and prohibits the recording of additional capital from restricted stock until those instruments vest. With the adoption of SFAS 123-R, pro forma disclosure of the impact of share-based payments to employees is no longer an alternative. | |
The provisions of SFAS 123-R generally apply to awards granted after the required effective date of the statement, which was January 1, 2006 for the company. The company has elected the modified prospective method of application and, accordingly, has not restated previously reported financial condition, operating results or the presentation of cash flows. The elimination of additional capital associated with unvested restricted shares resulted in an offsetting reversal of unamortized executive stock plan expense upon implementation of SFAS 123-R. Additionally, the presentation of cash flows for 2006 has been modified to reflect the benefits of tax deductions for stock compensation in excess of recognized compensation cost as financing cash flows, as now required. | ||
The companys director and executive stock plans are described, and informational disclosures provided, in the Notes to the Consolidated Financial Statements included in the Form 10-K for the year ended December 31, 2005. The contractual lives of 2006 awards, which have included |
7
stock options and stock appreciation rights, are consistent with those of prior years. Restricted stock awards totaling 271,000 shares have been granted in 2006 at a weighted-average per share price of $84, vesting over five years. |
During the three and nine month periods ended September 30, 2006, the company recognized pretax compensation expense, including the impact on expense of retirement eligibility discussed below, of $1.2 million ($0.01 per diluted share after-tax) and $3.4 million ($0.02 per diluted share after-tax), respectively, associated with stock options. Current year expense includes amounts arising from stock option awards during the first quarter of 2006 to purchase 260,000 shares at a weighted-average price of $84 per share, with annual vesting of 20 percent. The $26 per share weighted-average fair value of 2006 option grants was determined using the Black-Scholes option-pricing model and assumptions of a 4.74 year average life, 4.6 percent risk-free interest rate, 1 percent expected dividend yield and 30 percent historical volatility. Previously under APB 25, no compensation cost was recognized for unvested stock options where the grant price was equal to the market price on the date of grant and the vesting provisions were based only on the passage of time. Had the company recorded compensation expense using the accounting method required by SFAS 123-R, net earnings and earnings per share for the three and nine month periods ended September 30, 2005 would have been reduced to the pro forma amounts as follows: |
Three Months | Nine Months | |||||||
Ended | Ended | |||||||
September 30, | September 30, | |||||||
$ in thousands, except per share amounts | 2005 | 2005 | ||||||
Net earnings |
||||||||
As reported |
$ | 131,189 | $ | 162,150 | ||||
Stock-based employee compensation expense, net of tax |
(334 | ) | (1,588 | ) | ||||
Pro forma |
$ | 130,855 | $ | 160,562 | ||||
Basic net earnings per share |
||||||||
As reported |
$ | 1.54 | $ | 1.92 | ||||
Pro forma |
$ | 1.54 | $ | 1.90 | ||||
Diluted net earnings per share |
||||||||
As reported |
$ | 1.51 | $ | 1.88 | ||||
Pro forma |
$ | 1.51 | $ | 1.86 | ||||
The company has not historically considered retirement eligibility in determining stock-based compensation expense, including expense associated with stock options and restricted stock. The adoption of SFAS 123-R required the company to assume the first date on which an employee becomes eligible to retire in determining the amortization period for stock-based awards. For example, if the employee is eligible for retirement two years from the date of grant, the amortization period is to be no longer than two years rather than the specified service period over which awards normally vest. Retirement eligibility has been considered in the determination of periodic expense on a prospective basis for current year awards, and compensation expense associated with awards granted in prior periods have continued to be recognized using historical straight-line amortization practices based on award specific vesting periods. |
The impact of using retirement eligibility in determining all stock option expense would have been to decrease the pro forma adjustments shown above by approximately 65 percent for the three and nine month periods ended September 30, 2005. The impact of using retirement eligibility to determine amortization periods for all restricted stock awards would have been to increase |
8
recorded restricted stock amortization expense of $4.3 million and $13.8 million by approximately one-third during the 2005 three and nine month periods, respectively. The impact of using retirement eligibility to determine amortization periods for 2006 stock option and restricted stock awards was to increase pretax amortization expense by approximately $0.8 million and $2.4 million, respectively, for an aggregate after-tax impact of $0.02 per diluted share during the three months ended September 30, 2006. The corresponding impacts for the nine months ended September 30, 2006 were pretax increases of $2.1 million for stock options and $6.2 million for restricted stock that had a total impact of $0.06 per diluted share after-tax. | ||
The average trading price of the companys stock during the first nine months of 2006 was
$86 per share. During the nine months ended September 30, 2006, 439,000 stock options were
exercised at a weighted average exercise price of $34 per share. As of September 30, 2006,
there were 692,000 stock options outstanding with a weighted average exercise price of $51
per share, of which 436,000 were exercisable with a weighted average exercise price of $31
per share. As of September 30, 2006 and December 31, 2005, there were 1,237,000 and
1,498,000 unvested shares, respectively, of restricted stock outstanding. The balances of
unamortized stock option and restricted stock expense at September 30, 2006 were $3.4
million and $38.5 million, respectively. |
||
(7) | Operations are organized in five industry segments: Oil & Gas, Industrial & Infrastructure, Government, Global Services and Power. The Oil & Gas segment provides engineering, procurement and construction professional services for upstream oil and gas production, downstream refining and certain petrochemicals markets. The Industrial & Infrastructure segment provides engineering, procurement and construction professional services for manufacturing and life sciences facilities, commercial and institutional buildings, mining, microelectronics, telecommunications and transportation projects and other facilities. The Government segment provides project management, engineering, construction and contingency response services to the United States government, which represents a significant customer. The Global Services segment includes operations and maintenance, construction equipment, temporary staffing and global procurement services. The Power segment provides professional services to engineer and construct power generation facilities. | |
Operating information by segment is as follows for the three and nine months ended September 30, 2006 and 2005: |
Three Months Ended | Nine Months Ended | |||||||||||||||
External Revenue | September 30 | September 30 | ||||||||||||||
($ in millions) | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Oil & Gas |
$ | 1,382.5 | $ | 1,447.5 | $ | 3,875.4 | $ | 3,844.4 | ||||||||
Industrial & Infrastructure |
800.3 | 857.3 | 2,312.3 | 2,085.5 | ||||||||||||
Government |
550.3 | 651.3 | 2,500.2 | 1,859.6 | ||||||||||||
Global Services |
484.4 | 367.8 | 1,427.2 | 1,116.0 | ||||||||||||
Power |
146.5 | 94.6 | 330.2 | 292.7 | ||||||||||||
Total external revenue |
$ | 3,364.0 | $ | 3,418.5 | $ | 10,445.3 | $ | 9,198.2 | ||||||||
9
Three Months Ended | Nine Months Ended | |||||||||||||||
Operating Profit (Loss) | September 30 | September 30 | ||||||||||||||
($ in millions) | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Oil & Gas |
$ | 86.8 | $ | 84.1 | $ | 220.0 | $ | 188.0 | ||||||||
Industrial & Infrastructure |
21.5 | 43.5 | 52.9 | 0.5 | ||||||||||||
Government |
(95.2 | ) | 20.9 | 8.0 | 49.5 | |||||||||||
Global Services |
31.5 | 26.5 | 107.0 | 81.3 | ||||||||||||
Power |
2.0 | 5.9 | 4.7 | 12.0 | ||||||||||||
Total operating profit |
$ | 46.6 | $ | 180.9 | $ | 392.6 | $ | 331.3 | ||||||||
A reconciliation of the segment information to consolidated amounts for the three and nine months ended September 30, 2006 and 2005 is as follows: |
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in millions | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Total segment operating profit |
$ | 46.6 | $ | 180.9 | $ | 392.6 | $ | 331.3 | ||||||||
Corporate administrative and
general expense |
32.6 | 25.1 | 128.7 | 90.9 | ||||||||||||
Interest (income) expense, net |
0.1 | (1.7 | ) | 0.7 | (3.2 | ) | ||||||||||
Earnings before taxes |
$ | 13.9 | $ | 157.5 | $ | 263.2 | $ | 243.6 | ||||||||
The following table summarizes non-operating (income) and expense items reported in administrative and general expense: |
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in millions | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Sales of portfolio properties |
$ | | $ | (10.4 | ) | $ | | $ | (14.6 | ) | ||||||
Impairment of investment |
| 2.0 | 3.6 | 2.0 | ||||||||||||
Other items |
(0.5 | ) | 0.2 | 1.3 | 2.4 | |||||||||||
Total |
$ | (0.5 | ) | $ | (8.2 | ) | $ | 4.9 | $ | (10.2 | ) | |||||
Total assets in the Oil & Gas segment increased to $650 million at September 30, 2006 from $575 million at December 31, 2005 due to additional working capital associated with the higher level of project execution activities. Total assets in the Industrial & Infrastructure segment increased to $545 million at September 30, 2006 from $490 million at December 31, 2005 as the principal result of costs incurred in connection with the National Roads Telecommunications Services project discussed in Note 11 below. Total assets in the Global Services segment increased to $725 million at September 30, 2006 from $640 million at December 31, 2005 as the principal result of investments in equipment and inventories to support the 2006 revenue growth. Total assets in the Government segment decreased to $698 million at September 30, 2006 from $905 million at December 31, 2005 as the principal result of cash collections from and reduced activity levels in Federal Emergency Management Agency and Iraq reconstruction projects. Government segment assets include unbilled fees totaling $130.0 million on the Fernald project at September 30, 2006, of which $112.6 million are included in other current assets and $17.4 million are included in other assets in the accompanying Condensed Consolidated Balance Sheet. |
10
(8) | During 2004, the company issued $330 million of 1.5 percent Convertible Senior Notes (the Notes) due 2024, realizing net proceeds of $323 million. In December 2004, the company irrevocably elected to pay the principal amount of the Notes in cash if a specified trading price of the companys common stock (the trigger price) is achieved and maintained for a specified period and the Notes are presented by the holders for conversion. During the fourth quarter of 2005 and the first three quarters of 2006, the trigger price was achieved for the specified number of days and the Notes have therefore been classified as short-term debt as of September 30, 2006 and December 31, 2005. |
In December 2004, the company filed a shelf registration statement for the issuance of up to $500 million of any combination of debt securities or common stock, the proceeds from which could be used for debt retirement, the funding of working capital requirements or other corporate purposes. Pursuant to the shelf registration statement, the company subsequently entered into a distribution agreement for up to 2,000,000 shares of common stock. During the nine months ended September 30, 2005, the company sold 758,367 shares under this distribution agreement, realizing net proceeds of $41.8 million. |
During the third quarter of 2006 the company entered into an amended credit facility maturing in 2011 that provides for revolving loans and letters of credit up to $1.5 billion. The company now has a total of $2.0 billion of committed and uncommitted lines of credit to support the issuance of letters of credit. At September 30, 2006, $655 million of these lines of credit were used to support outstanding letters of credit. |
(9) | Net periodic pension expense for defined benefit pension plans includes the following components: |
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in thousands | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Service cost |
$ | 8,725 | $ | 5,466 | $ | 25,982 | $ | 23,633 | ||||||||
Interest cost |
10,988 | 9,467 | 32,558 | 31,361 | ||||||||||||
Expected return on assets |
(15,271 | ) | (12,943 | ) | (45,255 | ) | (39,672 | ) | ||||||||
Amortization of transition asset |
2 | 3 | 7 | 9 | ||||||||||||
Amortization of prior service cost |
(29 | ) | (27 | ) | (87 | ) | (82 | ) | ||||||||
Recognized net actuarial loss |
4,803 | 3,019 | 14,261 | 11,773 | ||||||||||||
Net periodic pension expense |
$ | 9,218 | $ | 4,985 | $ | 27,466 | $ | 27,022 | ||||||||
During the third quarter of 2005, the company implemented a plan design change to a non-U.S. defined benefit plan, retroactive to January 1, 2005 and revised certain assumptions for the plan. The impact of these changes was a reduction of $7.7 million to net periodic pension expense for the year, $5.8 million of which was included in the net periodic pension expense for the three and nine months ended September 30, 2005. |
The company currently expects to contribute approximately $50 million to $70 million to the plans during 2006 compared with $89 million funded in 2005. During the nine months ended September 30, 2006, contributions of approximately $11 million were made by the company. |
11
Net periodic postretirement benefit cost includes the following components: |
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in thousands | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Service cost |
$ | | $ | | $ | | $ | | ||||||||
Interest cost |
386 | 400 | 1,156 | 1,200 | ||||||||||||
Expected return on assets |
| | | | ||||||||||||
Amortization of prior service cost |
| | | | ||||||||||||
Recognized net actuarial loss |
280 | 225 | 840 | 675 | ||||||||||||
Net periodic postretirement
benefit cost |
$ | 666 | $ | 625 | $ | 1,996 | $ | 1,875 | ||||||||
The preceding information does not include amounts related to benefit plans applicable to employees associated with certain contracts with the U.S. Department of Energy because the company is not responsible for the current or future funded status of these plans. | ||
In September 2006, the FASB issued SFAS No. 158, Employers Accounting for Defined Benefit Pension and Other Postretirement Plans (SFAS 158). This statement requires that the funded status of plans, measured as the difference between plan assets at fair value and the benefit obligations, be recognized in the statement of financial position and that various items be recognized in other comprehensive income before they are recognized in periodic benefit cost. Additional disclosures will also be required. The statement will apply to fiscal years ending after December 15, 2006. | ||
The company has not yet completed its assessment of the effects of applying the provisions of SFAS 158. However, the initial pretax reduction of comprehensive income upon adoption is expected to be approximately $300 million. | ||
(10) | The company and certain of its subsidiaries are involved in litigation in the ordinary course of business. The company and certain of its subsidiaries are contingently liable for commitments and performance guarantees arising in the ordinary course of business. Clients have made claims arising from engineering and construction contracts against the company, and the company has made claims against clients for costs incurred in excess of the current contract provisions. The company recognizes certain significant claims for recovery of incurred costs when it is probable that the claim will result in additional contract revenue and when the amount of the claim can be reliably estimated. Recognized claims against clients amounted to $193 million and $144 million at September 30, 2006 and December 31, 2005, respectively. Amounts ultimately realized from claims could differ materially from the balances included in the financial statements. The company does not expect that claim recoveries will have a material adverse effect on its consolidated financial position or results of operations. | |
As of September 30, 2006, several matters on certain completed and in-progress projects are in the dispute resolution process. The following discussion provides a background and current status of certain of these matters: | ||
Infrastructure Joint Venture Project | ||
The company participates in a 50/50 joint venture that is executing a fixed-price transportation infrastructure project in California. The project continues to be subject to circumstances including owner-directed scope changes leading to quantity growth, cost escalation, additional labor and |
12
schedule delays, resulting in additional costs. During the third quarter of 2006 additional charges of $22.3 million were recorded. The company continues to evaluate the impact of these circumstances on estimated total project costs, as well as claims for recoveries and other contingencies on the project. | ||
To date, the joint venture has submitted claims totaling approximately $125 million to the client. Costs of $56 million have been incurred by the joint venture relating to these claims as of September 30, 2006 and the company has recognized its $28 million proportionate share of these costs in revenue. | ||
London Connect Project | ||
The company is involved in arbitration proceedings in connection with its London Connect Project (LUL), a $500 million lump sum project to design and install a telecommunications network that allows reception and transmissions throughout the London Underground system. In February 2005, the company sought relief through arbitration proceedings for two issues. First, the company is seeking relief for the overall delay and disruption to the project that relates to the contract time period of 2001 through 2003. The arbitration hearing on this matter has been held and the company is anticipating a decision from the arbitrator prior to the end of 2006. A claim for delay and disruption subsequent to 2003 has been submitted to the dispute resolution process. Costs incurred of $69 million relating to delay and disruption for the entire contract period have been recognized as claims. The second issue concerns the responsibility for enabling the various train stock to accept the new telecommunication network equipment. Hearings involving LUL, the company and Motorola, a subcontractor, are completed and the parties await the arbitration decision. | ||
Embassy Projects | ||
The company has been performing work on 11 embassy projects for the United States Department of State under fixed-price contracts over the last two years. Five projects remain under construction and are in various stages of completion. These projects have been adversely impacted by higher costs due to schedule extensions, scope changes causing material deviations from the Standard Embassy Design, increased costs to meet client requirements for additional security-cleared labor, site conditions at certain locations, subcontractor difficulties and the availability and productivity of construction labor. Civil unrest in Haiti along with other factors has caused significant schedule delays resulting in increased costs. These unanticipated difficult operating conditions encountered on this project have caused the company to revise the execution strategy which is reflected in the current estimate to complete. The Haiti project is approximately 25 percent complete and because construction activity will continue for another 18 to 24 months actual costs could vary from the current estimate. Projects in Kazakhstan, Jamaica and Belize will be completed and the facilities will be occupied by December 2006. The project in Greece will be completed in early 2007. | ||
During the third quarter of 2006, the company recognized provisions totaling $133 million for estimated cost overruns on these uncompleted projects, including substantial amounts relating to the embassy in Haiti, where periods of civil unrest have resulted in significant schedule delays and cost increases. In addition, increased cost has resulted from collapsible soil conditions at the site, additional client imposed requirements and subsequent increases in material quantities, and the availability and productivity of construction labor. During the second quarter of 2006 the company recognized $21 million in cost overruns on embassy projects in Kazakhstan and Jamaica bringing the total provisions recognized to $154 million for the nine months ended September 30, 2006. The company recognized provisions for estimated cost overruns on certain of the embassy projects totaling $42 million in the nine months ended September 30, 2005. |
13
Claims for equitable adjustment on seven of the projects totaling approximately $81 million have been submitted or identified to date. As the first formal step in dispute resolution, the majority of these claims have now been certified in accordance with federal contracting requirements. As of September 30, 2006, $59 million in costs relating to these claims have been incurred and recognized in revenue. Additional claims continue to be evaluated. | ||
Fluor Daniel International and Fluor Arabia Ltd. v. General Electric Company, et al | ||
In October 1998, Fluor Daniel International and Fluor Arabia Ltd. filed a complaint in the United States District Court for the Southern District of New York against General Electric Company and certain operating subsidiaries as well as Saudi American General Electric, a Saudi Arabian corporation. The complaint seeks damages in connection with the procurement, engineering and construction of the Rabigh Combined Cycle Power Plant in Saudi Arabia. Subsequent to a motion to compel arbitration of the matter, the company initiated arbitration proceedings in New York under the American Arbitration Association international rules. The evidentiary phase of the arbitration has been concluded. In January 2005 the arbitration panel indicated that it would be rendering its decision in two phases; the first to be a decision on entitlement and second, a decision on damages. On May 4, 2005 the arbitration panel issued a partial award on entitlement issues which confirmed Fluors entitlement to recovery of certain of its claims for costs incurred in construction of the plant. A decision determining the amount recoverable has yet to be issued by the arbitration panel. | ||
Dearborn Industrial Project Duke/Fluor Daniel (D/FD) |
||
The Dearborn Industrial Project (the Project) started as a co-generation combined cycle power plant project in Dearborn, Michigan. The initial Turnkey Agreement, dated November 24, 1998, consisted of three phases. Commencing shortly after Notice to Proceed, the owner/operator, Dearborn Industrial Generation (DIG), issued substantial change orders enlarging the scope of the project. | ||
The Project was severely delayed with completion of Phase II. DIG unilaterally took over completion and operation of Phase II and commissioned that portion of the plant. Shortly thereafter, DIG drew upon a $30 million letter of credit which Duke/Fluor Daniel (D/FD) expects to recover upon resolution of the dispute. D/FD retains lien rights (in fee) against the project. In October 2001, D/FD commenced an action in Michigan State Court to foreclose on the lien interest. | ||
In December 2001, DIG filed a responsive pleading denying liability and simultaneously served a demand for arbitration to D/FD claiming, among other things, that D/FD is liable to DIG for alleged construction delays and defective engineering and construction work at the Dearborn plant. The court has ordered the matter to arbitration. The lien action remains stayed pending completion of the arbitration of D/FDs claims against DIG and DIGs claims against D/FD. The arbitration proceedings have been completed and a decision from the arbitrators is anticipated prior to the end of 2006. | ||
(11) | In the ordinary course of business, the company enters into various agreements providing financial or performance assurances to clients on behalf of certain unconsolidated partnerships, joint ventures and other jointly executed contracts. These agreements are entered into primarily to support the project execution commitments of these entities. The guarantees have various expiration dates ranging from mechanical completion of the facilities being constructed to a period |
14
extending beyond contract completion in certain circumstances. The maximum potential payment amount of an outstanding performance guarantee is the remaining cost of work to be performed by or on behalf of third parties under engineering and construction contracts. Amounts that may be required to be paid in excess of estimated costs to complete contracts in progress are not estimable. For cost reimbursable contracts, amounts that may become payable pursuant to guarantee provisions are normally recoverable from the client for work performed under the contract. For lump sum or fixed price contracts, this amount is the cost to complete the contracted work less amounts remaining to be billed to the client under the contract. Remaining billable amounts could be greater or less than the cost to complete. In those cases where costs exceed the remaining amounts payable under the contract the company may have recourse to third parties, such as owners, co-venturers, subcontractors or vendors for claims. As of September 30, 2006, no material changes to financial or performance assurances to clients had occurred since the filing of the companys December 31, 2005 annual report on Form 10-K, other than reductions in the amount of such guarantees arising from progress towards completion of contracts. |
Financial guarantees, made in the ordinary course of business on behalf of clients and others in certain limited circumstances, are entered into with financial institutions and other credit grantors and generally obligate the company to make payment in the event of a default by the borrower. Most arrangements require the borrower to pledge collateral in the form of property, plant and equipment which is deemed adequate to recover amounts the company might be required to pay. As of September 30, 2006, no material changes to financial guarantees of the debt of third parties had occurred since the filing of the companys December 31, 2005 annual report on Form 10-K and the carrying value of recorded guarantee obligations was not significant as of either of those dates. |
The company has a joint venture arrangement to design, build, finance and maintain an aircraft refueling facility at a United States Air Force base in Qatar for the Defense Energy Support Center, an agency of the Department of Defense. The company has a 27.5 percent interest in the joint venture company. On April 29, 2005, the joint venture entered into an agreement for project financing which includes joint and several project completion guarantees by the members of the joint venture. The maximum potential amount of future payments that could be required under the guarantee is $76.5 million, the maximum principal amount available under the financing arrangement, plus any accrued interest. The facility is presently over 80 percent complete, with completion expected in early 2007. | ||
National Roads Telecommunications Services (NRTS) Project |
During 2005 the companys Industrial & Infrastructure segment was awarded a $544 million project by a joint venture, GeneSYS Telecommunications Limited (GeneSYS), which is consolidated in the companys consolidated financial statements. The project was entered into with the United Kingdom Secretary of State for Transport (the Highways Agency) to design, build, maintain and finance a new integrated transmission network throughout Englands motorways. The project will be executed by GeneSYS, in which the company owns a 45 percent interest, and HSBC Infrastructure Fund Management Limited, which owns a 55 percent interest. GeneSYS will finance the engineering and construction (E&C) of upgraded telecommunications infrastructure with approximately $240 million (£140 million) of non-recourse debt (the term loan facility) from a consortium of lenders (the Banks) along with joint venture member capital contributions totaling approximately $37 million (£22 million). The equity contributions by the joint venture members have been provided through equity bridge loans from the Banks. The loans have been guaranteed or secured in proportion to each members equity participation. The equity bridge loans are repayable upon completion of the upgrade at which time the equity members are required to fund their contributions to the joint venture. |
15
During construction, the availability of the existing telecommunications network will be maintained for the Highways Agency by GeneSYS. Upon completion of the upgrade, operating availability of the network will be provided to the Highways Agency and the system will be fully maintained by GeneSYS. Under this arrangement, GeneSYS is entitled to payments from the Highways Agency for network availability, operations and maintenance (O&M) plus fees for on-demand maintenance services. The company has been engaged by GeneSYS to provide design engineering and construction of the network as well as O&M and on-demand services for the existing and upgraded facilities under a subcontract extending through 2016. | ||
Based on a qualitative analysis of the operations of GeneSYS and the variable interests of all parties to the arrangement, under the provisions of FIN 46-R the company has been determined to be the primary beneficiary of the joint venture. The companys financial statements include the accounts of GeneSYS, and, accordingly, the non-recourse debt provided by the Banks totaling $138.7 million and $57.6 million at September 30, 2006 and December 31, 2005, respectively. | ||
The term loan facility provides for interest only at LIBOR plus a margin of 95 basis points during construction of the upgraded facilities reducing to a margin of 90 basis points after completion of construction and continuing until fully repaid. Commitment fees are payable on unused portions of the facility. Payments are due in installments over the term of the services period ending in 2016. | ||
The term loan facility is an obligation of GeneSYS and will never be a debt obligation of the company because it is non-recourse to the joint venture members. Accordingly, in the event of a default on the term loans, the lenders may only look to the resources of GeneSYS for repayment. The debt will never be repayable from assets of the company beyond its gross $17 million equity investment plus any un-remitted profits in the venture. | ||
The contract has been segmented between the E&C and O&M portions of the work to be performed. The E&C portion of the work is being accounted for using contract accounting revenue recognition principles. Revenue in connection with O&M services including on-demand services will be recognized as earned through the life of the contract. | ||
(12) | As of the end of the second quarter of 2006, the previously announced relocation of the companys corporate headquarters from Southern California to Irving, Texas was completed. Approximately 120 employees in Southern California who did not relocate to Texas left the company. The cost of these employee displacements was accrued ratably starting in the third quarter of 2005 through the date of the employee departures. All other relocation and hiring costs are charged to expense as incurred. | |
For the quarter and nine months ended September 30, 2006, corporate administrative and general expenses include $3.1 million and $14.4 million, respectively, for relocation costs, which comprise the accrual of employee displacement costs and other direct expenses. Additional relocation costs of approximately $2 million are expected to be incurred during the fourth quarter of 2006, which will also be included in corporate administrative and general expense. | ||
The corporate facility in Aliso Viejo was sold in September 2005. A short-term, market rate lease-back was negotiated with the buyer that terminated on June 30, 2006. The cost of the new Texas headquarters totaled $60 million and was funded from available cash resources including proceeds from the sale of the former headquarters facility. |
16
| Difficulties or delays incurred in the execution of construction contracts, including performance by our joint venture partners, resulting in cost overruns or liabilities; |
| A failure to obtain favorable results in existing or future litigation or dispute resolution proceedings; |
| The potential impact of certain tax matters including, but not limited to, those from foreign operations and the ongoing audits by tax authorities and those resulting from the companys reverse spin-off transaction involving the companys former coal segment; |
| Changes in global business, economic (including currency risk), political and social conditions; |
| The companys failure to receive anticipated new contract awards and the related impacts on staffing levels and costs; |
| Customer cancellations of, or scope adjustments to, existing contracts, including our government contracts that may be terminated at any time; |
| Unanticipated losses that may arise on fixed price projects as a result of factors such as civil unrest, security issues, labor conditions and other unforeseeable events; |
| The cyclical nature of many of the markets the company serves and its vulnerability to downturns; |
| Failure to meet timely completion or performance standards could result in higher costs and reduced profits or, in some cases losses on projects; |
| Customer delays or defaults in making payments; |
| The companys ability to hire and retain qualified personnel; |
| Possible limitations of bonding capacity; |
| The availability of credit and restrictions imposed by credit facilities; |
| Limitations on cash transfers from subsidiaries may restrict the companys ability to satisfy financial obligations, or to pay interest or principal when due on outstanding debt; |
| Competition in the global engineering, procurement and construction industry; |
| The companys ability to identify and successfully integrate acquisitions; |
| The impact of past and future environmental, health and safety regulations; and | |
| Restrictions on possible transactions imposed by Delaware law. |
17
18
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in millions | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Revenues |
$ | 1,382.5 | $ | 1,447.5 | $ | 3,875.4 | $ | 3,844.4 | ||||||||
Operating profit |
86.8 | 84.1 | 220.0 | 188.0 |
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in millions | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Revenues |
$ | 800.3 | $ | 857.3 | $ | 2,312.3 | $ | 2,085.5 | ||||||||
Operating profit |
21.5 | 43.5 | 52.9 | 0.5 |
19
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in millions | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Revenues |
$ | 550.3 | $ | 651.3 | $ | 2,500.2 | $ | 1,859.6 | ||||||||
Operating profit (loss) |
(95.2 | ) | 20.9 | 8.0 | 49.5 |
20
21
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in millions | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Revenues |
$ | 484.4 | $ | 367.8 | $ | 1,427.2 | $ | 1,116.0 | ||||||||
Operating profit |
31.5 | 26.5 | 107.0 | 81.3 |
Three Months Ended | Nine Months Ended | |||||||||||||||
September 30 | September 30 | |||||||||||||||
$ in millions | 2006 | 2005 | 2006 | 2005 | ||||||||||||
Revenues |
$ | 146.5 | $ | 94.6 | $ | 330.2 | $ | 292.7 | ||||||||
Operating profit |
2.0 | 5.9 | 4.7 | 12.0 |
22
23
24
25
26
27
28
Three Months Ended | ||||||||
September 30 | ||||||||
(in millions) | 2006 | 2005 | ||||||
Backlog beginning of period |
$ | 18,030.2 | $ | 15,666.4 | ||||
New awards |
4,790.7 | 2,533.3 | ||||||
Adjustments and cancellations, net |
245.0 | (195.0 | ) | |||||
Work performed |
(3,275.9 | ) | (3,342.2 | ) | ||||
Backlog end of period |
$ | 19,790.0 | $ | 14,662.5 | ||||
Nine Months Ended | ||||||||
September 30 | ||||||||
(in millions) | 2006 | 2005 | ||||||
Backlog beginning of period |
$ | 14,926.6 | $ | 14,765.8 | ||||
New awards |
14,372.1 | 9,114.3 | ||||||
Adjustments and cancellations, net |
658.6 | (211.5 | ) | |||||
Work performed |
(10,167.3 | ) | (9,006.1 | ) | ||||
Backlog end of period |
$ | 19,790.0 | $ | 14,662.5 | ||||
29
(c) | The following table provides information about purchases by the company during the quarter ended September 30, 2006 of equity securities that are registered by the company pursuant to Section 12 of the Exchange Act: |
Total Number | ||||||||||||||||
of Shares | Maximum | |||||||||||||||
Purchased | Number of | |||||||||||||||
as Part of | Shares that May | |||||||||||||||
Average | Publicly | Yet Be | ||||||||||||||
Total Number | Price | Announced | Purchased | |||||||||||||
of Shares | Paid per | Plans or | Under the Plans | |||||||||||||
Period | Purchased(1) | Share | Programs | or Program (2) | ||||||||||||
July 1, 2006 July 31, 2006 |
1 | $ | 84.96 | N/A | 4,141 | |||||||||||
August 1, 2006 August 31, 2006 |
| | N/A | 4,141 | ||||||||||||
September 1, 2006 September 30, 2006 |
15 | $ | 81.48 | N/A | 4,141 | |||||||||||
Total |
16 | $ | 81.69 | |||||||||||||
(1) | Shares cancelled as payment for statutory withholding taxes, in thousands, upon the vesting of restricted stock issued pursuant to equity based employee benefit plans. | |
(2) | On September 20, 2001, the company announced that the Board of Directors had approved the repurchase of up to five million shares of our common stock. That authorization is ongoing and does not have an expiration date. |
30
Exhibit | Description | |
3.1
|
Amended and Restated Certificate of Incorporation of the registrant (1) | |
3.2
|
Amended and Restated Bylaws of the registrant (10) | |
4.1
|
Indenture between Fluor Corporation and Bank of New York, as trustee dated as of February 17, 2004 (2) | |
10.1
|
Distribution Agreement between the registrant and Fluor Corporation (renamed Massey Energy Company) (3) | |
10.2
|
Tax Sharing Agreement between Fluor Corporation and A.T. Massey Coal Company, Inc.(4) | |
10.3
|
Fluor Corporation 2000 Executive Performance Incentive Plan, as amended and restated as of March 30, 2005 (9) | |
10.4
|
Fluor Corporation 2000 Restricted Stock Plan for Non-Employee Directors, as amended and restated on August 2, 2006 (11) | |
10.5
|
Fluor Corporation Executive Deferred Compensation Plan, as amended and restated effective January 1, 2002 (5) | |
10.6
|
Fluor Corporation Deferred Directors Fees Program, as amended and restated effective January 1, 2002 (6) | |
10.7
|
Directors Life Insurance Summary (1) | |
10.8
|
Fluor Executives Supplemental Benefit Plan (1) | |
10.9
|
Fluor Corporation Retirement Plan for Outside Directors (1) | |
10.10
|
Executive Severance Plan (7) | |
10.11
|
2001 Key Employee Performance Incentive Plan, as amended and restated as of March 30, 2005 (9) | |
10.12
|
2001 Fluor Stock Appreciation Rights Plan (5) | |
10.13
|
Fluor Corporation 2003 Executive Performance Incentive Plan, as amended and restated as of March 30, 2005 (9) | |
10.14
|
Form of Compensation Award Agreements for grants under the Fluor Corporation 2003 Executive Performance Incentive Plan (8) | |
10.15
|
Offer of Employment Letter dated May 7, 2001 from Fluor Corporation to D. Michael Steuert (7) | |
10.16
|
Amended and Restated Credit Agreement, dated as of September 7, 2006 among Fluor Corporation, BNP Paribas, as Administrative Agent and an Issuing Lender, Citicorp USA, Inc., as Syndication Agent, Bank of America, N.A. and The Bank of Tokyo-Mitsubishi UFJ, Ltd., as Co-Documentation Agents, and the lenders party thereto * | |
10.17
|
Special Retention Agreement, dated March 27, 2006, between Fluor Corporation and John Hopkins (11) | |
31.1
|
Certification of Chief Executive Officer of Fluor Corporation * | |
31.2
|
Certification of Chief Financial Officer of Fluor Corporation * |
31
Exhibit | Description | |
32.1
|
Certification of Chief Executive Officer pursuant to Rule 13a-14(b) or Rule 15d-14(b) of the Securities Exchange Act of 1934 and 18 U.S.C. Section 1350 * | |
32.2
|
Certification of Chief Financial Officer pursuant to Rule 13a-14(b) or Rule 15d-14(b) of the Securities Exchange Act of 1934 and 18 U.S.C. Section 1350 * |
* | New exhibit filed with this report. | |
(1) | Filed as an exhibit to the Registrants Registration Statement on Form 10/A (Amendment No. 1) filed on November 22, 2000 and incorporated herein by reference. | |
(2) | Filed as an exhibit to the Registrants report on Form 8-K filed on February 17, 2004 and incorporated herein by reference. | |
(3) | Filed as Exhibit 10.1 to the Registrants report on Form 8-K dated December 7, 2000 and incorporated herein by reference. | |
(4) | Filed as Exhibit 10.2 to the Registrants report on Form 8-K dated December 7, 2000 and incorporated herein by reference. | |
(5) | Filed as an exhibit to the Registrants report on Form 10-K filed on March 21, 2002 and incorporated herein by reference. | |
(6) | Filed as an exhibit to the Registrants report on Form 10-K filed on March 31, 2003 and incorporated herein by reference. | |
(7) | Filed as an exhibit to the Registrants report on Form 10-K filed on March 15, 2004 and incorporated herein by reference. | |
(8) | Filed as an exhibit to the Registrants report on Form 10-Q filed on November 9, 2004 and incorporated herein by reference. | |
(9) | Filed as an exhibit to the Registrants report on Form 10-Q filed on May 5, 2005 and incorporated herein by reference. | |
(10) | Filed as an exhibit to the Registrants report on Form 10-Q filed on May 8, 2006 and incorporated herein by reference. | |
(11) | Filed as an exhibit to the Registrants report on Form 10-Q filed on August 7, 2006 and incorporated herein by reference. |
32
FLUOR CORPORATION |
||||
Date: November 6, 2006 | /s/ D. Michael Steuert | |||
D. Michael Steuert | ||||
Senior Vice President and Chief Financial Officer | ||||
Date: November 6, 2006 | /s/ V.L. Prechtl | |||
V. L. Prechtl | ||||
Vice President and Controller |
33
Exhibit | Description | |
3.1
|
Amended and Restated Certificate of Incorporation of the registrant (1) | |
3.2
|
Amended and Restated Bylaws of the registrant (10) | |
4.1
|
Indenture between Fluor Corporation and Bank of New York, as trustee dated as of February 17, 2004 (2) | |
10.1
|
Distribution Agreement between the registrant and Fluor Corporation (renamed Massey Energy Company) (3) | |
10.2
|
Tax Sharing Agreement between Fluor Corporation and A.T. Massey Coal Company, Inc.(4) | |
10.3
|
Fluor Corporation 2000 Executive Performance Incentive Plan, as amended and restated as of March 30, 2005 (9) | |
10.4
|
Fluor Corporation 2000 Restricted Stock Plan for Non-Employee Directors, as amended and restated on August 2, 2006 (11) | |
10.5
|
Fluor Corporation Executive Deferred Compensation Plan, as amended and restated effective January 1, 2002 (5) | |
10.6
|
Fluor Corporation Deferred Directors Fees Program, as amended and restated effective January 1, 2002 (6) | |
10.7
|
Directors Life Insurance Summary (1) | |
10.8
|
Fluor Executives Supplemental Benefit Plan (1) | |
10.9
|
Fluor Corporation Retirement Plan for Outside Directors (1) | |
10.10
|
Executive Severance Plan (7) | |
10.11
|
2001 Key Employee Performance Incentive Plan, as amended and restated as of March 30, 2005 (9) | |
10.12
|
2001 Fluor Stock Appreciation Rights Plan (5) | |
10.13
|
Fluor Corporation 2003 Executive Performance Incentive Plan, as amended and restated as of March 30, 2005 (9) | |
10.14
|
Form of Compensation Award Agreements for grants under the Fluor Corporation 2003 Executive Performance Incentive Plan (8) | |
10.15
|
Offer of Employment Letter dated May 7, 2001 from Fluor Corporation to D. Michael Steuert (7) | |
10.16
|
Amended and Restated Credit Agreement dated as of September 7, 2006 among Fluor Corporation, BNP Paribas, as Administrative Agent and an Issuing Lender, Citicorp USA, Inc., as Syndication Agent, Bank of America, N.A. and The Bank of Tokyo-Mitsubishi UFJ, Ltd., as Co-Documentation Agents, and the lenders party thereto * | |
10.17
|
Special Retention Agreement, dated March 27, 2006, between Fluor Corporation and John Hopkins (11) | |
31.1
|
Certification of Chief Executive Officer of Fluor Corporation * | |
31.2
|
Certification of Chief Financial Officer of Fluor Corporation * |
34
Exhibit | Description | |
32.1
|
Certification of Chief Executive Officer pursuant to Rule 13a-14(b) or Rule 15d-14(b) of the Securities Exchange Act of 1934 and 18 U.S.C. Section 1350 * | |
32.2
|
Certification of Chief Financial Officer pursuant to Rule 13a-14(b) or Rule 15d-14(b) of the Securities Exchange Act of 1934 and 18 U.S.C. Section 1350 * |
* | New exhibit filed with this report. | |
(1) | Filed as an exhibit to the Registrants Registration Statement on Form 10/A (Amendment No. 1) filed on November 22, 2000 and incorporated herein by reference. | |
(2) | Filed as an exhibit to the Registrants report on Form 8-K filed on February 17, 2004 and incorporated herein by reference. | |
(3) | Filed as Exhibit 10.1 to the Registrants report on Form 8-K dated December 7, 2000 and incorporated herein by reference. | |
(4) | Filed as Exhibit 10.2 to the Registrants report on Form 8-K dated December 7, 2000 and incorporated herein by reference. | |
(5) | Filed as an exhibit to the Registrants report on Form 10-K filed on March 21, 2002 and incorporated herein by reference. | |
(6) | Filed as an exhibit to the Registrants report on Form 10-K filed March 31, 2003 and incorporated herein by reference. | |
(7) | Filed as an exhibit to the Registrants report on Form 10-K filed on March 15, 2004 and incorporated herein by reference. | |
(8) | Filed as an exhibit to the Registrants report on Form 10-Q filed on November 9, 2004 and incorporated herein by reference. | |
(9) | Filed as an exhibit to the Registrants report on Form 10-Q filed on May 5, 2005 and incorporated herein by reference. | |
(10) | Filed as an exhibit to the Registrants report on Form 10-Q filed on May 8, 2006 and incorporated herein by reference. | |
(11) | Filed as an exhibit to the Registrants report on Form 10-Q filed on August 7, 2006 and incorporated herein by reference. |
35