Edgar Filing: TUTOR PERINI Corp

Three Months Ended March 31,

(in millions)

Income from construction operations

20160331 Q1

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

FORM 10-Q

☒QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the quarterly period ended March 31, 2016

☐TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the transition period from to

Commission File Number: 1-6314

Tutor Perini Corporation

(Exact name of registrant as specified in its charter)


MASSACHUSETTS		04-1717070
(State or other jurisdiction of incorporation or organization)		(I.R.S. Employer Identification No.)

15901 OLDEN STREET, SYLMAR, CALIFORNIA 91342-1093

(Address of principal executive offices)

(Zip code)

(818) 362-8391

(Registrant’s telephone number, including area code)

(Former name, former address and former fiscal year, if changed since last report)

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes ☒ No ☐

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate website, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes ☒ No ☐

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act. (Check one):


Large accelerated filer ☒		Accelerated filer ☐

Non-Accelerated filer ☐		Smaller reporting company ☐

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes ☐ No ☒

The number of shares of common stock, $1.00 par value per share, of the registrant outstanding at May 2, 2016 was 49,072,710.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

INDEX


			Page Number
Part I.	Financial Information:
	Item 1.	Financial Statements (Unaudited)
		Condensed Consolidated Statements of Operations for the Three Months Ended March 31, 2016 and 2015 (Unaudited)	3
		Condensed Consolidated Statements of Comprehensive Income for the Three Months Ended March 31, 2016 and 2015 (Unaudited)	4
		Condensed Consolidated Balance Sheets as of March 31, 2016 and December 31, 2015 (Unaudited)	5
		Condensed Consolidated Statements of Cash Flows for the Three Months Ended March 31, 2016 and 2015 (Unaudited)	6
		Notes to the Condensed Consolidated Financial Statements	7-23
	Item 2.	Management’s Discussion and Analysis of Financial Condition and Results of Operations	24-29
	Item 3.	Quantitative and Qualitative Disclosures About Market Risk	29
	Item 4.	Controls and Procedures	29
Part II.	Other Information:
	Item 1.	Legal Proceedings	30
	Item 1A.	Risk Factors	30
	Item 2.	Unregistered Sales of Equity Securities and Use of Proceeds	30
	Item 3.	Defaults Upon Senior Securities	30
	Item 4.	Mine Safety Disclosures	30
	Item 5.	Other Information	30
	Item 6.	Exhibits	31
	Signatures		32

Table of Contents

PART I. – FINANCIAL INFORMATION

Item 1. – Financial Statements

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS

UNAUDITED



	Three Months Ended
	March 31,
(in thousands, except per share amounts)	2016		2015
REVENUE	$	1,085,369	$	1,066,465
COST OF OPERATIONS		(980,277)		(975,706)
GROSS PROFIT		105,092		90,759
General and administrative expenses		(64,970)		(70,675)
INCOME FROM CONSTRUCTION OPERATIONS		40,122		20,084
Other income (expense), net		682		(754)
Interest expense		(14,080)		(11,125)
INCOME BEFORE INCOME TAXES		26,724		8,205
Provision for income taxes		(11,324)		(3,079)
NET INCOME	$	15,400	$	5,126

BASIC EARNINGS PER COMMON SHARE	$	0.31	$	0.11
DILUTED EARNINGS PER COMMON SHARE	$	0.31	$	0.10

WEIGHTED-AVERAGE COMMON SHARES OUTSTANDING:
BASIC		49,079		48,747
DILUTED		49,285		49,543

The accompanying notes are an integral part of these Condensed Consolidated Financial Statements.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME

UNAUDITED



	Three Months Ended
	March 31,
(in thousands)	2016		2015
NET INCOME	$	15,400	$	5,126

OTHER COMPREHENSIVE (LOSS) INCOME, NET OF TAX:
Defined benefit pension plan adjustments		247		—
Foreign currency translation adjustment		930		(588)
Unrealized (loss) gain in fair value of investments		8		(10)
Unrealized (loss) gain in fair value of interest rate swap		(35)		45
Total other comprehensive (loss) income, net of tax		1,150		(553)

TOTAL COMPREHENSIVE INCOME	$	16,550	$	4,573

The accompanying notes are an integral part of these Condensed Consolidated Financial Statements.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATED BALANCE SHEETS

UNAUDITED



(in thousands, except share and per share amounts)	March 31, 2016		December 31, 2015
ASSETS
CURRENT ASSETS:
Cash and cash equivalents	$	90,582	$	75,452
Restricted cash		49,158		45,853
Accounts receivable, including retainage of $488,043 and $484,255		1,615,661		1,473,615
Costs and estimated earnings in excess of billings		858,356		905,175
Deferred income taxes		26,550		26,306
Other current assets		91,990		108,844
Total current assets		2,732,297		2,635,245
PROPERTY AND EQUIPMENT (net of accumulated depreciation of $265,195 and $254,477)		519,890		523,525
OTHER ASSETS:
GOODWILL		585,006		585,006
INTANGIBLE ASSETS, NET		95,654		96,540
OTHER ASSETS		198,635		196,361
TOTAL ASSETS	$	4,131,482	$	4,036,677

LIABILITIES AND STOCKHOLDERS’ EQUITY
CURRENT LIABILITIES:
Current maturities of long-term debt	$	99,970	$	88,917
Accounts payable, including retainage of $204,386 and $204,767		1,005,906		937,464
Billings in excess of costs and estimated earnings		285,582		288,311
Accrued expenses and other current liabilities		160,964		159,016
Total current liabilities		1,552,422		1,473,708
LONG-TERM DEBT, less current maturities (net of unamortized discount and debt issuance cost of $10,948 and $6,697)		725,763		728,767
DEFERRED INCOME TAXES		274,232		273,310
OTHER LONG-TERM LIABILITIES		138,734		140,665
Total liabilities		2,691,151		2,616,450
CONTINGENCIES AND COMMITMENTS (NOTE 6)
STOCKHOLDERS' EQUITY:
Preferred stock - authorized 1,000,000 shares ($1 par value), none issued		—		—
Common stock - authorized 75,000,000 shares ($1 par value), issued and outstanding 49,072,710 shares		49,073		49,073
Additional paid-in capital		1,039,070		1,035,516
Retained earnings		393,203		377,803
Accumulated other comprehensive loss		(41,015)		(42,165)
TOTAL STOCKHOLERS' EQUITY		1,440,331		1,420,227

TOTAL LIABILITIES AND STOCKHOLERS' EQUITY	$	4,131,482	$	4,036,677

The accompanying notes are an integral part of these Condensed Consolidated financial statements.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

UNAUDITED



	Three Months Ended
	March 31,
(in thousands)	2016		2015
Cash Flows from Operating Activities:
Net income	$	15,400	$	5,126
Adjustments to reconcile net income to net cash from operating activities:
Depreciation and amortization		14,496		10,594
Share-based compensation expense		3,647		9,159
Deferred income taxes		(155)		—
(Gain) loss on sale of property and equipment		285		(276)
Other long-term liabilities		(4,061)		2,381
Other non-cash items		1,399		(2,227)
Changes in other components of working capital		(15,067)		(27,081)
NET CASH PROVIDED BY (USED IN) OPERATING ACTIVITIES		15,944		(2,324)

Cash Flows from Investing Activities:
Acquisition of property and equipment excluding financed purchases		(4,812)		(5,691)
Proceeds from sale of property and equipment		939		798
Change in restricted cash		(3,305)		277
NET CASH USED IN INVESTING ACTIVITIES		(7,178)		(4,616)

Cash Flows from Financing Activities:
Proceeds from debt		299,785		280,200
Repayment of debt		(287,484)		(262,112)
Issuance of common stock and effect of cashless exercise		—		(773)
Debt issuance costs		(5,937)		—
NET CASH PROVIDED BY FINANCING ACTIVITIES		6,364		17,315

Net increase in cash and cash equivalents		15,130		10,375
Cash and cash equivalents at beginning of year		75,452		135,583
Cash and cash equivalents at end of period	$	90,582	$	145,958

The accompanying notes are an integral part of these Condensed Consolidated financial statements.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

UNAUDITED

(1) Basis of Presentation

The Condensed Consolidated Financial Statements do not include footnotes and certain financial information normally presented annually under accounting principles generally accepted in the United States and, therefore, should be read in conjunction with the audited consolidated financial statements and the related notes included in the Company’s Annual Report on Form 10-K for the year ended December 31, 2015. Accounting measurements at interim dates inherently involve greater reliance on estimates than at year-end. The results of operations for the three months ended March 31, 2016 may not necessarily be indicative of results that can be expected for the full year.

In the opinion of management, the accompanying unaudited Condensed Consolidated Financial Statements reflect all adjustments, including those of a normal recurring nature, necessary to present fairly the Company’s consolidated financial position as of March 31, 2016 and its consolidated results of operations and cash flows for the interim periods presented. All significant intercompany transactions of consolidated subsidiaries are eliminated. Management has evaluated all material events occurring subsequent to the date of the financial statements up to the filing of this Form 10-Q.

(2) Recent Accounting Pronouncements

In the first quarter of 2016, the Company adopted ASU 2015-03, Interest – Imputation of Interest (Subtopic 835-30). This ASU requires companies to present, in the balance sheet, debt issuance costs related to a recognized debt liability as a direct deduction from the carrying amount of that debt liability, consistent with debt discounts. In addition, the amortization of that debt discount is required to be presented as a component of interest expense. The Company applied this guidance retrospectively, effective January 1, 2016; accordingly, the Company reclassified unamortized debt issuance costs of $5.8 million out of Other Assets and to Long-Term Debt, less current maturities in its December 31, 2015 Condensed Consolidated Balance Sheet.

In March 2016, the FASB issued ASU No. 2016-09, Improvement to Employee Share-Based Payment Accounting (Topic 718), which simplifies several aspects of the accounting for employee share-based payments including: accounting for income taxes, forfeitures and statutory tax withholding requirements. The ASU recognizes all tax differences between the book expense and tax deduction through the income statement, eliminating the notion of an additional paid-in capital pool; the ASU allows an entity to elect either to continue to estimate the total number of awards for the which the requisite service period will not be rendered, as is current practice, or to account for forfeitures when they occur; the ASU stipulates that the net settlement of an award for statutory tax withholding purposes would not result, by itself, in liability classification of the award provided the amount withheld does not exceed the employee’s relevant maximum tax rate. This ASU is effective for fiscal years beginning after December 15, 2016, including interim periods within those fiscal years. The adoption of this ASU is not expected to have a material impact on the Company’s financial statements.

In March 2016, the FASB issued ASU No. 2016-07, Equity Method and Joint Ventures (Topic 323), which eliminates the requirement that an entity retroactively adopt the equity method of accounting if an investment qualifies for use of the equity method as a result of an increase in the level of ownership. Instead, an equity method investor adds the cost of acquiring the additional interest to the current basis of the previously held interest and adopts the equity method of accounting as of the date the investment becomes qualified as such. This ASU is effective for fiscal years beginning after December 15, 2016 including interim periods within those fiscal years. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

In February 2016, the FASB issued ASU No. 2016-02, Leases (Topic-842), which amends the existing guidance in ASC 840 Leases. This amendment requires the recognition of lease assets and lease liabilities by lessees for those leases currently classified as operating leases. Other significant provisions of the amendment include (i) defining the “lease term” to include the non-cancellable period together with periods for which there is a significant economic incentive for the lessee to extend or not terminate the lease; (ii) defining the initial lease liability to be recorded on the balance sheet to contemplate only those variable lease payments that depend on an index or that are in substance “fixed”; and (iii) a dual approach for determining whether lease expense is recognized on a straight-line or accelerated basis, depending on whether the lessee is expected to consume more than an insignificant portion of the leased asset’s economic benefits. This ASU is effective for fiscal years beginning after December 15, 2018, including interim periods within those fiscal years. Lessees and lessors are required to use a modified retrospective transition method for existing leases. Accordingly, they would apply the new accounting model for the earliest year presented in the financial statements. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

In November 2015, the FASB issued ASU 2015-17, Balance Sheet Classification of Deferred Taxes (Subtopic 740-10). This ASU requires entities to present all deferred tax assets and all deferred tax liabilities as noncurrent in a classified balance sheet. This ASU is effective for fiscal years, and interim periods within those years, beginning after December 15, 2016. The Company had $26.6 million of current deferred tax assets and $24.9 million of current deferred tax liabilities as of March 31 2016, which will be presented as noncurrent upon adoption of this ASU.

In May 2014, the FASB issued ASU No. 2014-09, Revenue from Contracts with Customers (Topic 606), which provides a single comprehensive accounting standard for revenue recognition for contracts with customers and supersedes current industry-specific guidance, including ASC 605-35. The new standard prescribes a five-step revenue recognition model that focuses on transfer of control and entitlement to consideration in determining the amount of revenue to be recognized. The guidance also significantly expands qualitative and quantitative disclosure requirements regarding the nature, amount, timing and uncertainty of revenue and cash flows arising from contracts with customers. The standard is effective for the Company for fiscal years beginning after December 15, 2017 and interim periods within those years. The adoption will result in retrospective application, either in the form of recasting all prior periods presented or a cumulative adjustment to equity in the period of adoption. The Company is currently evaluating the effect that the adoption of this ASU will have on its financial statements.

(3) Earnings per Share (EPS)

Basic EPS is calculated by dividing net income by the weighted-average number of common shares outstanding during the period, to which dilutive securities are included in the calculation of diluted EPS, using the treasury stock method. The calculations of the basic and diluted EPS for the three months ended March 31, 2016 and 2015 are presented below:



	Three Months Ended March 31,
(in thousands, except per share data)	2016		2015
Net income	$	15,400	$	5,126

Weighted-average common shares outstanding - basic		49,079		48,747
Effect of diluted stock options and unvested restricted stock		206		796
Weighted-average common shares outstanding - diluted		49,285		49,543

Net income per share:
Basic	$	0.31	$	0.11
Diluted	$	0.31	$	0.10
Anti-dilutive securities not included above		1,704		529

(4) Costs and estimated earnings in excess of billings

Reported costs and estimated earnings in excess of billings consists of the following:



	March 31,		December 31,
(in thousands)	2016		2015
Claims	$	395,708	$	407,164
Unapproved change orders		224,297		270,019
Other unbilled costs and profits		238,351		227,992
Total costs and estimated earnings in excess of billings	$	858,356	$	905,175

The prerequisite for billing claims and unapproved change orders is the final resolution and agreement between the parties. The prerequisite for billing other unbilled costs and profits is defined in the billing terms of each of the applicable contracts.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

(5) Financial Commitments

Long-Term Debt

Long-term debt consists of the following:



	March 31,		December 31,
(in thousands)	2016		2015
Senior Notes	$	297,366	$	297,118
Revolving Credit Facility		178,738		155,815
Term Loan		220,198		222,120
Equipment financing, mortgages and acquisition-related notes		124,911		133,288
Other indebtedness		4,520		9,343
Total debt		825,733		817,684
Less – current maturities		(99,970)		(88,917)
Long-term debt, net	$	725,763	$	728,767

The following table reconciles the outstanding debt balance to the reported debt balances as of March 31, 2016 and December 31, 2015.



	March 31, 2016						December 31, 2015
(in thousands)	Outstanding Long-Term Debt		Unamortized Discount and Issuance Cost		Reported Long-Term Debt		Outstanding Long-Term Debt		Unamortized Discount and Issuance Cost		Reported Long-Term Debt
Senior Notes	$	300,000	$	(2,634)	$	297,366	$	300,000	$	(2,882)	$	297,118
Revolving Credit Facility		183,500		(4,762)		178,738		158,000		(2,185)		155,815
Term Loan		223,750		(3,552)		220,198		223,750		(1,630)		222,120

The discount and debt issuance cost related to the Senior Notes is amortized as interest expense based on an imputed interest rate of 7.99%. The debt issuance cost related to the Revolving Credit Facility and Term Loan (as defined below) is amortized as interest expense based on an imputed interest rate of 8.84%.

Amended Credit Agreement

On February 26, 2016, we entered into Waiver and Amendment No. 1 (the “Amendment”) to the Sixth Amended and Restated Credit Agreement (the “Original Facility”; collectively, the “Credit Facility”) with Bank of America, N.A., as Administrative Agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders. As a result of the Company’s financial results for the fiscal year ended December 31, 2015, which included the previously reported $23.9 million non-cash, pre-tax charge from an adverse ruling on the Brightwater litigation matter in the third quarter as well as $45.6 million of pre-tax charges in the third and fourth quarters for Five Star Electric, the Company was not in compliance with the required consolidated leverage ratio and consolidated fixed charge coverage ratio under the Original Facility, which are both calculated on a rolling four quarter basis. In the Amendment, the lenders waived these covenant violations and modified certain provisions of the Original Facility.

The Credit Facility provides for a $300 million revolving credit facility (the “Revolver”) and a $250 million term loan (the “Term Loan”). As a result of the Amendment, both the Revolver and the Term Loan will now mature on May 1, 2018. The Term Loan principal payments have been modified to include certain additional principal payments, which will be applied against the balloon payment (discussed below). Borrowings under the Revolver bear interest, based either on Bank of America’s prime lending rate, plus an applicable margin, or the London Interbank Offered Rate (“LIBOR”), plus an applicable margin. Borrowings under the Term Loan bear interest based on LIBOR plus an applicable margin. Under the terms of the Amendment, for so long as the Company’s consolidated leverage ratio is greater than 3.5 to 1.0, it will not be permitted to make LIBOR-based borrowings and will therefore be subject to an increased interest rate on borrowings, with such rate being 100 basis points higher than the highest rate under the Original Facility while the Company’s consolidated leverage ratio is greater than 3.5 to 1.0 but not more than 4.0 to 1.0, and an additional 100 basis points higher while the Company’s consolidated leverage ratio is greater than 4.0 to 1.0. The Company also will be subject to increased commitment fees at these higher leverage ratio levels. In addition, until the Company’s consolidated leverage ratio goes below 3.5 to 1.0, LIBOR-based borrowings will convert to base rate borrowings. The Amendment provides for the exclusion of the impact of the Brightwater litigation matter from the calculation of the Company’s consolidated leverage ratio and

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

consolidated fixed charge coverage ratio. Interest payments will be due on a monthly basis, rather than a quarterly basis. If the Company is in compliance with the leverage and fixed charge ratio covenants provided in the Original Facility as of December 31, 2016, interest payments will again be due on a quarterly basis thereafter. The Amendment also removes the accordion feature of the Original Facility, which would have allowed either an increase of $300 million in the Revolver or the establishment of one or more new term loan commitments.

The Amendment also modifies several of the covenants in the Original Facility, including the Company’s maximum allowable consolidated leverage ratio to be at 4.25:1.00 in the first quarter of 2016, stepping down to 4.0:1.0 in the second and third quarters of 2016 and then returning to the Original Facility’s range of 3.25:1.00 to 3.00:1.00 beginning with the fourth quarter of 2016. The Credit Facility will continue to require the Company to maintain a minimum consolidated fixed charge coverage ratio of 1.25:1.00. Other usual and customary covenants for credit facilities of this type (such as, restrictions on the payment of dividends and share repurchases) were included in the Original Facility (subject to certain modifications made in the Amendment), while the Amendment adds covenants regarding the Company’s liquidity, including a cap on the cash balance in the Company’s bank account and a weekly minimum liquidity requirement (based on specified available cash balances and availability under the Revolver). The Amendment also requires the Company to achieve certain quarterly cash collection milestones and increases the lenders’ collateral package. Beginning in the fourth quarter of 2016, the Company will be required to make quarterly principal payments towards the Term Loan balloon payment, based on a percentage of certain forecasted cash collections for the prior quarter, in addition to the scheduled amortization payments of the Original Facility.

Substantially all of the Company’s subsidiaries unconditionally guarantee our obligations under the Credit Facility. The obligations under the Credit Facility are secured by a lien on substantially all real and personal property of the Company and its subsidiaries party thereto. Under the Amendment, the Company agreed to increase the lenders’ collateral package, including by pledging to the lenders (i) the equity interests of each direct domestic subsidiary of the Company and (ii) 65% of the stock of each material first-tier foreign restricted subsidiary of the Company.

We utilized the Revolver for letters of credit in the amount of $0.2 million as of March 31, 2016 and December 31, 2015. As of March 31, 2016, we had $116.3 million of additional capacity under the Revolver.

The Company was in compliance with the financial covenants under the Credit Facility for the period ended March 31, 2016.

(6) Contingencies and Commitments

The Company and certain of its subsidiaries are involved in litigation and are contingently liable for commitments and performance guarantees arising in the ordinary course of business. The Company and certain of its customers have made claims arising from the performance under their contracts. The Company recognizes certain significant claims for recovery of incurred cost when it is probable that the claim will result in additional contract revenue and when the amount of the claim can be reliably estimated. These assessments require judgments concerning matters such as litigation developments and outcomes, the anticipated outcome of negotiations, the number of future claims and the cost of both pending and future claims. In addition, because most contingencies are resolved over long periods of time, liabilities may change in the future due to various factors.

Several matters are in the litigation and dispute resolution process. The following discussion provides a background and current status of the more significant matters.

Long Island Expressway/Cross Island Parkway Matter

The Company reconstructed the Long Island Expressway/Cross Island Parkway Interchange project for the New York State Department of Transportation (the “NYSDOT”). The $130 million project was substantially completed in January 2004 and was accepted by the NYSDOT as finally complete in February 2006. The Company incurred significant added costs in completing its work and suffered extended schedule costs due to numerous design errors, undisclosed utility conflicts, lack of coordination with local agencies and other interferences for which the Company believes the NYSDOT is responsible.

In March 2011, the Company filed its claim and complaint with the New York State Court of Claims and served to the New York State Attorney General’s Office, seeking damages in the amount of $53.8 million. In May 2011, the NYSDOT filed a motion to dismiss the Company’s claim on the grounds that the Company had not provided required documentation for project closeout and filing of a claim. In September 2011, the Company reached agreement on final payment with the Comptroller’s Office on behalf of the NYSDOT which resulted in an amount of $0.5 million payable to the Company and formally closed out the project allowing the Company to re-file its claim. The Company re-filed its claim in the amount of $53.8 million with the NYSDOT in February 2012 and

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

with the Court of Claims in March 2012. In May 2012, the NYSDOT served its answer and counterclaims in the amount of $151 million alleging fraud in the inducement and punitive damages related to disadvantaged business enterprise (“DBE”) requirements for the project. The Court subsequently ruled that NYSDOT’s counterclaims may only be asserted as a defense and offset to the Company’s claims and not as affirmative claims. In November 2014, the Appellate Division First Department affirmed the dismissal of the City’s affirmative defenses and counterclaims based on DBE fraud. The Company does not expect the counterclaims to have any material effect on its consolidated financial statements.

Management has made an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the consolidated financial statements at that time.

Fontainebleau Matter

Desert Mechanical Inc. (“DMI”) and Fisk Electric Company (“Fisk”), wholly owned subsidiaries of the Company, were subcontractors on the Fontainebleau Project in Las Vegas (“Fontainebleau”), a hotel/casino complex with approximately 3,800 rooms. In June 2009, Fontainebleau filed for bankruptcy protection, under Chapter 11 of the U.S. Bankruptcy Code, in the Southern District of Florida. Fontainebleau is headquartered in Miami, Florida.

DMI and Fisk filed liens in Nevada for approximately $44 million, representing unreimbursed costs to date and lost profits, including anticipated profits. Other unaffiliated subcontractors have also filed liens. In June 2009, DMI filed suit against Turnberry West Construction, Inc., the general contractor, in the 8th Judicial District Court, Clark County, Nevada (the “District Court”), and in May 2010, the court entered an order in favor of DMI for approximately $45 million.

In January 2010, the Bankruptcy Court approved the sale of the property to Icahn Nevada Gaming Acquisition, LLC, and this transaction closed in February 2010. As a result of a July 2010 ruling relating to certain priming liens, there was approximately $125 million set aside from this sale, which is available for distribution to satisfy the creditor claims based on seniority. At that time, the total estimated sustainable lien amount was approximately $350 million. The project lender filed suit against the mechanic’s lien claimants, including DMI and Fisk, alleging that certain mechanic’s liens are invalid and that all mechanic’s liens are subordinate to the lender’s claims against the property. The Nevada Supreme Court ruled in October 2012 in an advisory opinion at the request of the Bankruptcy Court that lien priorities would be determined in favor of the mechanic lien holders under Nevada law.

In October 2013, a settlement was reached by and among the Statutory Lienholders and the other interested parties. The Bankruptcy Court appointed a mediator to facilitate the execution of that settlement agreement, but the mediator was unable to yield a settlement. DMI will file a Motion to Terminate Mediation and proceed with litigating its claims in the District Court.

Honeywell Street/Queens Boulevard Bridges Matter

In 1999, the Company was awarded a contract for reconstruction of the Honeywell Street/Queens Boulevard Bridges project for the City of New York (the “City”). In June 2003, after substantial completion of the project, the Company initiated an action to recover $8.8 million in claims against the City on behalf of itself and its subcontractors. In March 2010, the City filed counterclaims for $74.6 million and other relief, alleging fraud in connection with the DBE requirements for the project. In May 2010, the Company served the City with its response to the City’s counterclaims and affirmative defenses. In August 2013, the Court granted the Company’s motion to dismiss the City’s affirmative defenses and counterclaims relating to fraud. In September 2013, the City filed a Notice of Appeal to the Court’s decision; said appeal was dismissed by the Appellate Court in November 2014. A notice of trial has been filed.

The Company does not expect ultimate resolution of this matter to have any material effect on its consolidated financial statements.

Westgate Planet Hollywood Matter

Tutor-Saliba Corporation (“TSC”), a wholly owned subsidiary of the Company, contracted to construct a timeshare development project in Las Vegas which was substantially completed in December 2009. The Company’s claims against the owner, Westgate Planet Hollywood Las Vegas, LLC (“WPH”), relate to unresolved owner change orders and other claims. The Company filed a lien on the project in the amount of $23.2 million, and filed its complaint with the District Court, Clark County, Nevada. Several

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

subcontractors have also recorded liens, some of which have been released by bonds and some of which have been released as a result of subsequent payment. WPH has posted a mechanic’s lien release bond for $22.3 million.

WPH filed a cross-complaint alleging non-conforming and defective work for approximately $51 million, primarily related to alleged defects, misallocated costs, and liquidated damages. WPH revised the amount of their counterclaims to approximately $45 million.

Following multiple post-trial motions, final judgment was entered in this matter on March 20, 2014. TSC was awarded total judgment in the amount of $19.7 million on its breach of contract claim, which includes an award of interest up through the date of judgment, plus attorney’s fees and costs. WPH has paid $0.6 million of that judgment. WPH was awarded total judgment in the amount of $3.1 million on its construction defect claims, which includes interest up through the date of judgment. The awards are not offsetting. WPH and its Sureties have filed a notice of appeal. TSC has filed a notice of appeal on the defect award. In July 2014, the Court ordered WPH to post an additional supersedeas bond on appeal, in the amount of $1.7 million, in addition to the lien release bond of $22.3 million, which increases the security up to $24.0 million. The Nevada Supreme Court has not yet ruled on this matter.

The Company does not expect ultimate resolution of this matter to have any material effect on its consolidated financial statements. Management has made an estimate of the total anticipated recovery on this project and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the consolidated financial statements at that time.

U.S. Department of Commerce, National Oceanic and Atmospheric Administration Matter

Rudolph and Sletten, Inc. (“R&S”), a wholly owned subsidiary of the Company, entered into a contract with the United States Department of Commerce, National Oceanic and Atmospheric Administration (“NOAA”) for the construction of a 287,000 square-foot facility for NOAA’s Southwest Fisheries Science Center Replacement Headquarters and Laboratory in La Jolla, California. The contract work began on May 24, 2010, and was substantially completed in September 2012. R&S incurred significant additional costs as a result of a design that contained errors and omissions, NOAA’s unwillingness to correct design flaws in a timely fashion and a refusal to negotiate the time and pricing associated with change order work.

R&S has filed three certified claims against NOAA for contract adjustments related to the unresolved Owner change orders, delays, design deficiencies and other claims. The First Certified Claim was submitted on August 20, 2013, in the amount of $26.8 million ("First Certified Claim") and the Second Certified Claim was submitted on October 30, 2013, in the amount of $2.6 million ("Second Certified Claim") and the Third Certified Claim was submitted on October 1, 2014 in the amount of $0.7 million (“Third Certified Claim”).

NOAA requested an extension to issue a decision on the First Certified Claim and on the Third Certified Claim, but did not request an extension of time to review the Second Certified Claim. On January 6, 2014, R&S filed suit in the United States Federal Court of Claims on the Second Certified Claim plus interest and attorney's fees and costs. This was followed by a submission of a lawsuit on the First Certified Claim on July 31, 2014. In February 2015, the Court denied NOAA’s motion to dismiss the Second Certified Claim. In March 2015, the Contracting Officer issued decisions on all Claims accepting a total of approximately $1.0 million of claims and denying approximately $29.5 million of claims. On April 14, 2015, the Court consolidated the cases and has commenced discovery through mid-2016. No trial date has been set.

Five Star Electric Matter

In the third quarter of 2015, Five Star Electric Corp. ("Five Star"), a subsidiary of the Company that was acquired in 2011, entered into a tolling agreement related to an ongoing investigation being conducted by the United States Attorney for the Eastern District of New York (“USAO EDNY”). The tolling agreement extended the statute of limitations to avoid the expiration of any unexpired statute of limitations while the investigation is pending. Five Star has been cooperating with the USAO EDNY since late June 2014, when it was first made aware of the investigation, and has been providing information related to its use of certain minority-owned, women-owned, small and disadvantaged business enterprises and, in addition, most recently, information regarding certain of Five Star’s employee compensation, benefit and tax practices. The investigation covers the period of 2005-2014.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

The Company cannot predict the ultimate outcome of the investigation and cannot accurately estimate any potential liability that Five Star or the Company may incur or the impact of the results of the investigation on Five Star or the Company.

Alaskan Way Viaduct Matter

In January 2011, Seattle Tunnel Partners (“STP”), a joint venture between Dragados USA, Inc. and the Company, entered into a design-build contract with the Washington State Department of Transportation ("WSDOT") for the construction of a large diameter bored tunnel in downtown Seattle, King County, Washington to replace the Alaskan Way Viaduct, also known as State Route 99.

The construction of the large diameter bored tunnel requires the use of a tunnel boring machine (“TBM”). In December 2013, the TBM struck a steel pipe, installed by WSDOT as a well casing for an exploratory well. The TBM was damaged and was required to be shut down for repair. STP has asserted that the steel pipe casing was a differing site condition that WSDOT failed to properly disclose. The Disputes Review Board mandated by the contract to hear disputes issued a decision finding the steel casing was a Type I differing site condition. WSDOT has not accepted that finding.

The TBM is insured under a Builder’s Risk Insurance Policy (“the Policy”) with Great Lakes Reinsurance (UK) PLC and a consortium of other insurers (the “Insurers”). STP submitted the claims to the insurer and requested interim payments under the Policy. The Insurers refused to pay and denied coverage. In June 2015, STP filed a lawsuit in the King County Superior Court, State of Washington (“Washington Superior Court”) seeking declaratory relief concerning contract interpretation as well as damages as a result of the Insurers’ breach of its obligations under the terms of the Policy. WSDOT is deemed a plaintiff since WSDOT is an insured under the Policy and had filed its own claim for damages. Trial is scheduled for June 2017.

In October 2015, WSDOT filed a complaint against STP in the Washington Superior Court for breach of contract and declaratory relief concerning contract interpretation. The Complaint was dismissed upon motion by STP. In March 2016, WSDOT refiled action against STP in Thurston County Superior Court.

As of March 2016, the Company has concluded that the potential for a material adverse financial impact due to the Insurer’s and WSDOT’s respective legal actions are neither probable nor remote. Management has made an estimate of the total anticipated recovery on this project and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the financial statements at that time.

(7) Share-Based Compensation

The Company’s share-based compensation plan is described, and informational disclosures are provided, in the Notes to Consolidated Financial Statements included in the Form 10-K for the year ended December 31, 2015. In the first three months of 2016 and 2015, 483,387 and 291,500 restricted stock units were granted at weighted-average per share prices of $19.14 and $23.35, respectively. During the first three months of 2016 and 2015, the Company awarded 274,000 and 259,000 stock options at weighted-average exercise prices of $16.20 and $16.07 per share, respectively. The options expire ten years after the grant date. Both the restricted stock units and options granted in 2016 and 2015 vest upon the achievement of defined performance targets.

(8) Other Comprehensive Income (Loss)

The tax effects of the components of other comprehensive income (loss) are as follows:



	Three Months Ended						Three Months Ended
	March 31, 2016						March 31, 2015
(in thousands)	Before-Tax Amount		Tax (Expense) Benefit		Net-of-Tax Amount		Before-Tax Amount		Tax (Expense) Benefit		Net-of-Tax Amount
Other comprehensive income (loss):
Defined benefit pension plan adjustments	$	427	$	(180)	$	247	$	-	$	-	$	-
Foreign currency translation adjustment		1,604		(674)		930		(964)		376		(588)
Unrealized gain (loss) in fair value of investments		13		(5)		8		(16)		6		(10)
Unrealized gain (loss) in fair value of interest rate swap		(62)		27		(35)		74		(29)		45
Total other comprehensive income (loss)	$	1,982	$	(832)	$	1,150	$	(906)	$	353	$	(553)

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

The following tables present the changes in accumulated other comprehensive income (“AOCI”) balances by component (after tax) for the three months ended March 31, 2016 and 2015.



	For the Three Months Ended March 31, 2016
(in thousands)	Defined Benefit Pension Plan		Foreign Currency Translation		Unrealized Gain in Fair Value of Investments, net		Unrealized Gain (Loss) in Fair Value of Interest Rate Swap, net		Accumulated Other Comprehensive Income (Loss), Net
Balance at the beginning of the quarter	$	(38,242)	$	(4,603)	$	656	$	24	$	(42,165)
Other comprehensive income (loss) before reclassifications		—		930		8		(35)		903
Amounts reclassified from AOCI		247		—		—		—		247
Total other comprehensive income (loss)		247		930		8		(35)		1,150
Balance at the end of the quarter	$	(37,995)	$	(3,673)	$	664	$	(11)	$	(41,015)



	For the Three Months Ended March 31, 2015
(in thousands)	Defined Benefit Pension Plan		Foreign Currency Translation		Unrealized Loss in Fair Value of Investments, net		Unrealized Gain in Fair Value of Interest Rate Swap, net		Accumulated Other Comprehensive Income (Loss), Net
Balance at the beginning of the quarter	$	(40,268)	$	(1,389)	$	(110)	$	149	$	(41,618)
Other comprehensive income (loss)		—		(588)		(10)		45		(553)
Balance at the end of the quarter	$	(40,268)	$	(1,977)	$	(120)	$	194	$	(42,171)

The items reclassified out of AOCI and the corresponding location and impact on the Condensed Consolidated Statement of Operations are as follows:



	Location in	Three Months Ended
	Condensed Consolidated	March 31,
(in thousands)	Statements of Earnings	2016		2015
Defined benefit pension plan adjustments	Various accounts(1)	$	427	$	—
Income tax benefit	Income tax expense		(180)		—
Net of tax		$	247	$	—

(1)

Defined benefit pension plan adjustments were reclassified primarily to total cost of revenue and general and administrative expense.

(9) Income Taxes

The Company’s income tax provision was $11.3 million for the three months ended March 31, 2016, with an effective tax rate of 42.4% for the three months ended March 31, 2016, compared to $3.1 million with an effective tax rate of 37.5% for the same period in 2015. The effective tax rate for the first quarter of 2016 was unfavorably impacted by various discrete items, including certain state tax rate changes on deferred taxes. The effective tax rate in the first quarter of 2015 was favorably impacted by adjustments related to prior year tax positions.

(10) Fair Value Measurements

The fair value hierarchy established by ASC 820, Fair Value Measurements, prioritizes the use of inputs used in valuation techniques into the following three levels:

Level 1 — quoted prices in active markets for identical assets or liabilities

Level 2 — inputs are other than Level 1 inputs that are observable, either directly or indirectly

Level 3 — unobservable inputs

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

The following is a summary of financial statement items carried at estimated fair values measured on a recurring basis as of the dates presented:



	March 31, 2016								December 31, 2015
	Fair Value Hierarchy								Fair Value Hierarchy
(in thousands)	Total		Level 1		Level 2		Level 3		Total		Level 1		Level 2		Level 3
Assets:
Cash and cash equivalents (a)	$	90,582	$	90,582	$	—	$	—	$	75,452	$	75,452	$	—	$	—
Restricted cash (a)		49,158		49,158		—		—		45,853		45,853		—		—
Investments in lieu of retainage (b)		44,036		37,988		6,048		—		41,566		35,350		6,216		—
Total	$	183,776	$	177,728	$	6,048	$	—	$	162,871	$	156,655	$	6,216	$	—

Liabilities:
Interest rate swap contract (c)	$	17	$	—	$	17	$	—	$	45	$	—	$	45	$	—
Total	$	17	$	—	$	17	$	—	$	45	$	—	$	45	$	—

(a)

Cash, cash equivalents and restricted cash consist primarily of money market funds with original maturity dates of three months or less, for which fair value is determined through quoted market prices.

(b)

Investments in lieu of retainage are classified as accounts receivable and are comprised primarily of money market funds, U.S. Treasury Notes and other municipal bonds, the majority of which are rated Aa3 or better. The fair values of the U.S. Treasury Notes and municipal bonds are obtained from readily-available pricing sources for comparable instruments and, as such, the Company has classified these assets as Level 2.

(c)

The Company values the interest rate swap liability utilizing a discounted cash flow model that takes into consideration forward interest rates observable in the market and the counterparty’s risk.

The Company did not have transfers between Levels 1 and 2 for either financial assets or liabilities, during the three months ended March 31, 2016 or 2015.

The carrying amount of cash and cash equivalents approximates fair value due to the short-term nature of these items. The carrying value of receivables, payables and other amounts arising out of normal contract activities, including retainage, which may be settled beyond one year, is estimated to approximate fair value. Of the Company’s long-term debt, the fair values of the Senior Notes as of March 31, 2016 and December 31, 2015 were $295.5 million and $305.6 million, respectively, compared to the carrying value of $299.1 million and $299.0 million as of March 31, 2016 and December 31, 2015, respectively. The fair value of the Senior Notes was estimated using current observable market prices for the Company’s Senior Notes, which are Level 1 inputs. The reported value of the Company’s remaining long-term debt at March 31, 2016 and December 31, 2015 approximates fair value.

(11) Business Segments

The Company offers general contracting, pre-construction planning and comprehensive project management services, including planning and scheduling of the manpower, equipment, materials and subcontractors required for the timely completion of a project in accordance with the terms and specifications contained in a construction contract. The Company also offers self-performed construction services: site work, concrete forming and placement, steel erection, electrical, mechanical, plumbing and HVAC. As described further below, our business is conducted through three segments: Civil, Building and Specialty Contractors. These segments are determined based on how the Company’s Chairman and Chief Executive Officer (chief operating decision maker) aggregates business units when evaluating performance and allocating resources.

The Civil segment specializes in public works construction and the replacement and reconstruction of infrastructure. The civil contracting services include construction and rehabilitation of highways, bridges, mass-transit systems, and water management and wastewater treatment facilities.

The Building segment has significant experience providing services to a number of specialized building markets for private and public works customers, including the high-rise residential, hospitality and gaming, transportation, health care, commercial and government offices, sports and entertainment, education, correctional facilities, biotech, pharmaceutical, industrial and high-tech markets.

The Specialty Contractors segment specializes in electrical, mechanical, plumbing, HVAC, fire protection systems and pneumatically placed concrete for a full range of civil and building construction projects in the industrial, commercial, hospitality and gaming, and

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

mass-transit end markets. This segment provides the Company with unique strengths and capabilities, which allow the Company to position itself as a full-service contractor with greater control over scheduled work, project delivery and risk management.

The following table sets forth certain reportable segment information relating to the Company’s operations for the three months ended March 31, 2016 and 2015:


	Reportable Segments
					Specialty							Consolidated
(in thousands)	Civil			Building	Contractors		Totals		Corporate			Total
Three Months Ended March 31, 2016
Total revenue	$	367,501	$	487,994	$	281,773	$	1,137,268	$	—		$	1,137,268
Elimination of intersegment revenue		(31,643)		(20,256)		—		(51,899)		—			(51,899)
Revenue from external customers	$	335,858	$	467,738	$	281,773	$	1,085,369	$	—		$	1,085,369
Income from construction operations	$	33,665	$	12,450	$	9,413	$	55,528	$	(15,406)	(a)	$	40,122

Three Months Ended March 31, 2015
Total revenue	$	392,876	$	416,063	$	293,017	$	1,101,956	$	—		$	1,101,956
Elimination of intersegment revenue		(18,202)		(17,233)		(56)		(35,491)		—			(35,491)
Revenue from external customers	$	374,674	$	398,830	$	292,961	$	1,066,465	$	—		$	1,066,465
Income from construction operations	$	30,593	$	(2,279)	$	10,524	$	38,838	$	(18,754)	(a)	$	20,084

(a)

Consists primarily of corporate general and administrative expenses.

During the three months ended March 31, 2016, the Company recorded net favorable adjustments totaling $3.0 million in income from construction operations ($0.04 per diluted share) for various Five Star Electric projects in New York in the Specialty Contractors segment. The net impact included material adjustments related to two electrical subcontract projects: a favorable adjustment of $14.0 million for a completed project ($0.17 per diluted share) and an unfavorable adjustment of $13.8 million for a project that is nearly complete ($0.17 per diluted share).

There were no material changes in contract estimates at completion that impacted income from construction operations for the three months ended March 31, 2015.

Income from construction operations for the three months ended March 31, 2016 includes depreciation and amortization of $8.1 million for the Civil segment, $0.6 million for the Building segment, $1.3 million for the Specialty Contractors segment and $2.9 million for Corporate. Income from construction operations for the three months ended March 31, 2015 includes depreciation and amortization of $5.5 million for the Civil segment, $0.7 million for the Building segment, $1.4 million for the Specialty Contractors segment and $2.5 million for Corporate.

A reconciliation of segment results to the consolidated income before income taxes is as follows:



	Three Months Ended March 31,
(in thousands)	2016		2015
Income from construction operations	$	40,122	$	20,084
Other income (expense), net		682		(754)
Interest expense		(14,080)		(11,125)
Income before income taxes	$	26,724	$	8,205

Total assets by segment are as follows:



(in thousands)	March 31, 2016		December 31, 2015
Civil	$	1,947,787	$	1,964,038
Building		902,669		795,851
Specialty Contractors		843,379		860,285
Corporate and other (a)		437,647		416,503
Total Assets	$	4,131,482	$	4,036,677

(a)

Consists principally of cash and cash equivalents as well as corporate transportation and other equipment.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (CONTINUED)

UNAUDITED

(12) Employee Pension Plans

The Company has a defined benefit pension plan and an unfunded supplemental retirement plan. Effective September 1, 2004, all benefit accruals under these plans were frozen; however, the current vested benefit was preserved. The pension disclosure presented below includes aggregated amounts for both of the Company’s plans.

The following table sets forth the net periodic benefit cost for the three months ended March 31, 2016 and 2015:



	Three Months Ended March 31,
(in thousands)	2016		2015
Interest cost	$	1,053	$	1,011
Expected return on plan assets		(1,203)		(1,256)
Amortization of net loss		427		1,460
Other		150		—
Net periodic benefit cost	$	427	$	1,215

The Company contributed $0.3 million and $0.9 million to its defined benefit pension plan during the three months ended March 31, 2016 and 2015, respectively. The Company expects to contribute an additional $1.5 million to its defined benefit pension plan during the remainder of fiscal year 2016.

(13) Related Party Transactions

The Company leases certain facilities from an entity owned by Ronald N. Tutor, the Company’s Chairman and Chief Executive Officer, at market lease rates. Under these leases the Company paid $0.7 million for each of the three months ended March 31, 2016 and 2015, respectively, and recognized expense of $0.8 million for each of the three months ended March 31, 2016 and 2015, respectively.

Raymond R. Oneglia, Vice Chairman of O&G Industries, Inc. (“O&G”), is a director of the Company, and O&G owns 500,000 shares of the Company’s common stock. The Company and O&G formed a joint venture to provide contracting services for a highway construction project. O&G provides equipment and services to the joint venture on customary trade terms. The joint venture paid O&G $1.1 million and $2.0 million for the three months ended March 31, 2016 and 2015, respectively. The Company has a 30% percent interest in the joint venture, which it accounts for using the proportionate consolidation method.

Peter Arkley, Senior Managing Director, Construction Services Group, of Alliant Insurance Services, Inc. (“Alliant”), is a director of the Company. The Company uses Alliant for various insurance related services. The associated expenses for services provided for the three months ended March 31, 2016 and 2015 were $2.0 million and $0.8 million, respectively. The Company owed Alliant $1.9 million and $7.5 million as of March 31, 2016 and December 31, 2015, respectively, for services rendered.

(14) Separate Financial Information of Subsidiary Guarantors of Indebtedness

The Company’s obligations on its Senior Notes is guaranteed by substantially all of the Company’s existing and future subsidiaries that guarantee obligations under the Credit Facility (the “Guarantors”). The guarantees are full and unconditional as well as joint and several, and the Guarantors are 100%-owned by the Company.

The following supplemental condensed consolidating financial information reflects the summarized financial information of the Company as the issuer of the senior unsecured notes, the Guarantors and the Company’s non-guarantor subsidiaries on a combined basis.

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATING STATEMENT OF OPERATIONS

THREE MONTHS ENDED MARCH 31, 2016

UNAUDITED



					Non-
	Tutor Perini		Guarantor		Guarantor				Total
(in thousands)	Corporation		Subsidiaries		Subsidiaries		Eliminations		Consolidated
Revenue	$	176,725	$	986,361	$	7,104	$	(84,821)	$	1,085,369
Cost of operations		(154,289)		(910,809)		—		84,821		(980,277)
Gross profit	$	22,436	$	75,552	$	7,104	$	—	$	105,092
General and administrative expenses		(21,658)		(42,837)		(475)		—		(64,970)
Income from construction operations	$	778	$	32,715	$	6,629	$	—	$	40,122
Equity in earnings of subsidiaries		23,079		—		—		(23,079)		—
Other income (expense), net		(621)		1,060		243		—		682
Interest expense		(13,484)		(596)		—		—		(14,080)
Income (Loss) before income taxes	$	9,752	$	33,179	$	6,872	$	(23,079)	$	26,724
Benefit (Provision) for income taxes		5,648		(14,060)		(2,912)		—		(11,324)
Net income (loss)	$	15,400	$	19,119	$	3,960	$	(23,079)	$	15,400

Other comprehensive income (loss), net of tax:
Other comprehensive income of subsidiaries		938		—		—		(938)		—
Defined benefit pension plan adjustments		247		—		—		—		247
Foreign currency translation adjustment		—		930		—		—		930
Unrealized gain in fair value of investments		—		8		—		—		8
Unrealized loss in fair value of interest rate swap		(35)		—		—		—		(35)
Total other comprehensive (loss) income, net of tax	$	1,150	$	938	$	—	$	(938)	$	1,150

Total Comprehensive Income (Loss)	$	16,550	$	20,057	$	3,960	$	(24,017)	$	16,550

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATING STATEMENT OF OPERATIONS

THREE MONTHS ENDED MARCH 31, 2015

UNAUDITED



					Non-
	Tutor Perini		Guarantor		Guarantor				Total
(in thousands)	Corporation		Subsidiaries		Subsidiaries		Eliminations		Consolidated
Revenue	$	236,292	$	885,103	$	4,291	$	(59,221)	$	1,066,465
Cost of operations		(209,833)		(825,094)		—		59,221		(975,706)
Gross profit	$	26,459	$	60,009	$	4,291	$	—	$	90,759
General and administrative expenses		(25,035)		(45,166)		(474)		—		(70,675)
Income from construction operations	$	1,424	$	14,843	$	3,817	$	—	$	20,084
Equity in earnings of subsidiaries		11,940		—		—		(11,940)		—
Other income (expense), net		(2,068)		1,196		118		—		(754)
Interest expense		(10,264)		(861)		—		—		(11,125)
Income (Loss) before income taxes	$	1,032	$	15,178	$	3,935	$	(11,940)	$	8,205
Benefit (Provision) for income taxes		4,094		(5,696)		(1,477)		—		(3,079)
Net income (loss)	$	5,126	$	9,482	$	2,458	$	(11,940)	$	5,126

Other comprehensive income (loss), net of tax:
Other comprehensive income of subsidiaries		(598)		—		—		598		—
Defined benefit pension plan adjustments		—		—		—		—		—
Foreign currency translation adjustment		—		(588)		—		—		(588)
Unrealized loss in fair value of investments		—		(10)		—		—		(10)
Unrealized gain in fair value of interest rate swap		45		—		—		—		45
Total other comprehensive (loss) income, net of tax	$	(553)	$	(598)	$	—	$	598	$	(553)

Total Comprehensive Income (Loss)	$	4,573	$	8,884	$	2,458	$	(11,342)	$	4,573

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATING BALANCE SHEET

MARCH 31, 2016

UNAUDITED



					Non-
	Tutor Perini		Guarantor		Guarantor				Total
(in thousands)	Corporation		Subsidiaries		Subsidiaries		Eliminations		Consolidated
Assets
Current assets:
Cash and cash equivalents	$	49,726	$	40,151	$	705	$	—	$	90,582
Restricted cash		3,260		3,686		42,212		—		49,158
Accounts receivable		393,473		1,300,463		90,244		(168,519)		1,615,661
Costs and estimated earnings in excess of billings		115,635		816,642		152		(74,073)		858,356
Deferred income taxes		16,566		9,984		—		—		26,550
Other current assets		39,685		41,897		8,478		1,930		91,990
Total current assets	$	618,345	$	2,212,823	$	141,791	$	(240,662)	$	2,732,297
Property and equipment		102,371		413,513		4,006		—		519,890
Intercompany notes and receivables		—		270,676		—		(270,676)		—
Other Assets:
Goodwill		—		585,006		—		—		585,006
Intangible assets, net		—		95,654		—		—		95,654
Investment in subsidiaries		2,122,342		—		—		(2,122,342)		—
Other Assets		92,320		86,370		25,735		(5,790)		198,635
Total assets	$	2,935,378	$	3,664,042	$	171,532	$	(2,639,470)	$	4,131,482

Liabilities and stockholders' equity
Current liabilities:
Current maturities of long-term debt	$	125,255	$	34,715	$	—	$	(60,000)	$	99,970
Accounts payable		210,902		974,776		1,634		(181,406)		1,005,906
Billings in excess of costs and estimated earnings		88,888		198,182		593		(2,081)		285,582
Accrued expenses and other current liabilities		36,144		79,481		42,514		2,825		160,964
Total current liabilities	$	461,189	$	1,287,154	$	44,741	$	(240,662)	$	1,552,422
Long-term debt, less current maturities		655,029		76,524		—		(5,790)		725,763
Deferred income taxes		40,066		211,828		22,338		—		274,232
Other long-term liabilities		104,897		2,323		31,514		—		138,734
Intercompany notes and advances payable		233,866		—		36,810		(270,676)		—

Contingencies and commitments		—		—		—		—		—

Stockholders’ equity		1,440,331		2,086,213		36,129		(2,122,342)		1,440,331
Total liabilities and stockholders' equity	$	2,935,378	$	3,664,042	$	171,532	$	(2,639,470)	$	4,131,482

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATING BALANCE SHEET

DECEMBER 31, 2015

UNAUDITED



					Non-
	Tutor Perini		Guarantor		Guarantor				Total
(in thousands)	Corporation		Subsidiaries		Subsidiaries		Eliminations		Consolidated
Assets
Current assets:
Cash and cash equivalents	$	47,196	$	26,892	$	1,364	$	—	$	75,452
Restricted cash		3,369		3,283		39,201		—		45,853
Accounts receivable		358,437		1,179,919		82,004		(146,745)		1,473,615
Costs and estimated earnings in excess of billings		114,580		868,026		152		(77,583)		905,175
Deferred income taxes		2,255		21,356		2,695		—		26,306
Other current assets		60,119		48,482		11,662		(11,419)		108,844
Total current assets	$	585,956	$	2,147,958	$	137,078	$	(235,747)	$	2,635,245
Property and equipment		105,306		414,143		4,076		—		523,525
Intercompany notes and receivables		—		148,637		—		(148,637)		—
Other Assets:
Goodwill		—		585,006		—		—		585,006
Intangible assets, net		—		96,540		—		—		96,540
Investment in subsidiaries		1,962,983		—		—		(1,962,983)		—
Other Assets		58,722		128,094		15,268		(5,723)		196,361
Total assets	$	2,712,967	$	3,520,378	$	156,422	$	(2,353,090)	$	4,036,677

Liabilities and stockholders' equity
Current liabilities:
Current maturities of long-term debt	$	107,283	$	41,634	$	—	$	(60,000)	$	88,917
Accounts payable		211,679		890,268		3,222		(167,705)		937,464
Billings in excess of costs and estimated earnings		89,303		203,003		1,716		(5,711)		288,311
Accrued expenses and other current liabilities		6,145		115,392		39,810		(2,331)		159,016
Total current liabilities	$	414,410	$	1,250,297	$	44,748	$	(235,747)	$	1,473,708
Long-term debt, less current maturities		653,669		80,821		—		(5,723)		728,767
Deferred income taxes		—		273,310		—		—		273,310
Other long-term liabilities		106,588		3,278		30,799		—		140,665
Intercompany notes and advances payable		118,073		—		30,564		(148,637)		—

Contingencies and commitments		—		—		—		—		—

Stockholders’ equity		1,420,227		1,912,672		50,311		(1,962,983)		1,420,227
Total liabilities and stockholders' equity	$	2,712,967	$	3,520,378	$	156,422	$	(2,353,090)	$	4,036,677

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATING STATEMENT OF CASH FLOWS

THREE MONTHS ENDED MARCH 31, 2016

UNAUDITED



					Non-
	Tutor Perini		Guarantor		Guarantor				Total
(in thousands)	Corporation		Subsidiaries		Subsidiaries		Eliminations		Consolidated
Cash flows from operating activities:
Net income (loss)	$	15,400	$	19,119	$	3,960	$	(23,079)	$	15,400
Adjustments to reconcile net income to net cash from operating activities:
Depreciation and amortization		5,626		8,800		70		—		14,496
Equity in earnings of subsidiaries		(23,079)		—		—		23,079		—
Share-based compensation expense		3,647		—		—		—		3,647
Deferred income taxes		(153)		(2)		—		—		(155)
(Gain) loss on sale of property and equipment		202		83		—		—		285
Other long-term liabilities		(3,822)		(954)		715		—		(4,061)
Other non-cash items		(90)		1,489		—		—		1,399
Changes in other components of working capital		12,879		(25,578)		(2,368)		—		(15,067)
NET CASH PROVIDED BY OPERATING ACTIVITIES	$	10,610	$	2,957	$	2,377	$	—	$	15,944

Cash flows from investing activities:
Acquisition of property and equipment excluding financed purchases		(1,282)		(3,530)		—		—		(4,812)
Proceeds from sale of property and equipment		75		864		—		—		939
(Increase) decrease in intercompany advances		—		24,653		—		(24,653)		—
Change in restricted cash		109		(403)		(3,011)		—		(3,305)
NET CASH PROVIDED (USED) BY INVESTING ACTIVITIES	$	(1,098)	$	21,584	$	(3,011)	$	(24,653)	$	(7,178)

Cash flows from financing activities:
Proceeds from debt		299,785		—		—		—		299,785
Repayment of debt		(276,202)		(11,282)		—		—		(287,484)
Debt Issuance Costs		(5,937)		—		—		—		(5,937)
Increase (decrease) in intercompany advances		(24,628)		—		(25)		24,653		—
NET CASH PROVIDED (USED) BY FINANCING ACTIVITIES	$	(6,982)	$	(11,282)	$	(25)	$	24,653	$	6,364

Net (decrease) increase in cash and cash equivalents		2,530		13,259		(659)		—		15,130
Cash and cash equivalents at beginning of year		47,196		26,892		1,364		—		75,452
Cash and cash equivalents at end of period	$	49,726	$	40,151	$	705	$	—	$	90,582

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATING STATEMENT OF CASH FLOWS

THREE MONTHS ENDED MARCH 31, 2015

UNAUDITED



					Non-
	Tutor Perini		Guarantor		Guarantor				Total
(in thousands)	Corporation		Subsidiaries		Subsidiaries		Eliminations		Consolidated
Cash flows from operating activities:
Net income (loss)	$	5,126	$	9,482	$	2,458	$	(11,940)	$	5,126
Adjustments to reconcile net income to net cash from operating activities:
Depreciation and amortization		5,223		5,303		68		—		10,594
Equity in earnings of subsidiaries		(11,940)		—		—		11,940		—
Share-based compensation expense		9,159		—		—		—		9,159
Deferred income taxes		(24,392)		24,392		—		—		—
(Gain) loss on sale of investments		(17)		17		—		—		—
(Gain) loss on sale of property and equipment		17		(293)		—		—		(276)
Other long-term liabilities		(1,288)		3,669		—		—		2,381
Other non-cash items		1,176		(3,403)		—		—		(2,227)
Changes in other components of working capital		(73,266)		43,701		2,484		—		(27,081)
NET CASH PROVIDED (USED) BY OPERATING ACTIVITIES	$	(90,202)	$	82,868	$	5,010	$	—	$	(2,324)

Cash flows from investing activities:
Acquisition of property and equipment		(729)		(4,962)		—		—		(5,691)
Proceeds from sale of property and equipment		—		798		—		—		798
Decrease (increase) in intercompany advances		—		(57,146)		—		57,146		—
Change in restricted cash		—		283		(6)		—		277
NET CASH PROVIDED (USED) BY INVESTING ACTIVITIES	$	(729)	$	(61,027)	$	(6)	$	57,146	$	(4,616)

Cash flows from financing activities:
Proceeds from debt		280,200		—		—		—		280,200
Repayment of debt		(252,748)		(9,364)		—		—		(262,112)
Issuance of common stock and effect of cashless exercise		(773)		—		—		—		(773)
Increase (decrease) in intercompany advances		61,103		—		(3,957)		(57,146)		—
NET CASH PROVIDED (USED) BY FINANCING ACTIVITIES	$	87,782	$	(9,364)	$	(3,957)	$	(57,146)	$	17,315

Net (decrease) increase in cash and cash equivalents		(3,149)		12,477		1,047		—		10,375
Cash and cash equivalents at beginning of year		75,087		36,764		23,732		—		135,583
Cash and cash equivalents at end of period	$	71,938	$	49,241	$	24,779	$	—	$	145,958

Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

The following discusses our financial position at March 31, 2016 and the results of our operations for the three months ended March 31, 2016 and should be read in conjunction with: (1) the unaudited Condensed Consolidated Financial Statements and notes contained herein, and (2) the audited consolidated financial statements and accompanying notes to our Annual Report on Form 10-K for the fiscal year ended December 31, 2015.

Forward-Looking Statements

This Quarterly Report on Form 10-Q, including the “Management’s Discussion and Analysis of Financial Condition and Results of Operations,” contains forward-looking statements regarding future events and our future results, which are intended to be covered by the safe harbor provision for forward-looking statements provided by the Private Securities Litigation Reform Act of 1995. All statements other than statements of historical facts are statements that could be deemed forward-looking statements. Words such as “achieve,” “anticipate,” “assumes,” “believes,” “continue,” “could,” “estimate,” “expects,” “forecast,” “hope,” “intend,” “may,” “plan,” “potential,” “predict,” “should,” “will,” “would,” variations of such words, and similar expressions are intended to identify such forward-looking statements. In addition, any statements that refer to projections of our future financial performance, our anticipated growth and trends in our businesses, and other characterizations of future events or circumstances are forward-looking statements. Although such statements are based on currently available financial and economic data as well as management’s estimates and expectations, forward-looking statements are inherently uncertain and involve risks and uncertainties that could cause our actual results to differ materially from what may be inferred from the forward-looking statements. Therefore, actual results may differ materially and adversely from those expressed in any forward-looking statements. Factors potentially contributing to such differences include, among others:

A significant slowdown or decline in economic conditions;

Decreases in the level of government spending for infrastructure and other public projects;

Increased competition and failure to secure new contracts;

Failure to meet our obligations under our debt agreements;

Inaccurate estimates of contract risks, revenue or costs, which may result in lower than anticipated profits, or losses;

Client cancellations of, or reductions in scope under, contracts reported in our backlog;

Unfavorable outcomes of legal proceedings and failure to promptly recover significant working capital invested in projects subject to unresolved legal claims;

The requirement to perform extra, or change order, work, resulting in disputes or claims or adversely affecting our working capital, profits and cash flows;

Failure to meet contractual schedule requirements, which could result in higher cost and reduced profits or, in some cases, exposure to financial liability for liquidated damages and/or damages to customers;

Inability to retain key members of our management, to hire and retain personnel required to complete projects or implement succession plans for key officers;

Possible systems and information technology interruptions;

Failure of our joint venture partners to perform their venture obligations, which could impose additional financial and performance obligations on us, resulting in reduced profits or losses;

Failure to comply with laws and regulations related to government contracts;

Impairments of our goodwill or other indefinite-lived intangible assets;

Civil unrest, security issues, labor conditions and other unforeseeable events in the countries in which we do business, resulting in unanticipated losses.

Executive Overview

Consolidated revenue for the three months ended March 31, 2016 was $1.1 billion, an increase of 2% compared to the same period in 2015.

Income from construction operations for the three months ended March 31, 2016 was $40.1 million, about double compared to $20.1 million for the same period in 2015. The increase was principally due to increased activity on various mass-transit and building projects and lower general and administrative expenses.

The effective tax rate for the three months ended March 31, 2016 was 42.4% compared to 37.5% for three months ended March 31, 2015. See “Corporate, Tax and Other Matters” below for a detailed discussion of the changes in the effective tax rate.

Earnings per diluted share for three months ended March 31, 2016 as $0.31 compared to $0.10 for three months ended March 31, 2015. The strong increase was primarily due to the same factors that generated the increased income from construction operations, which are discussed above.

Table of Contents

Consolidated new awards for the three months ended March 31, 2016 were $1.8 billion compared to $1.0 billion for the three months ended March 31, 2015. The increase was driven by a $663 million mass-transit project in New York in the Civil segment and a $285 million hospitality and gaming project in California in the Building segment.

Consolidated backlog as of March 31, 2016 was $8.2 billion compared to $7.8 billion as of March 31, 2015. The increase was primarily due to the new awards mentioned above. As of March 31, 2016, the mix of backlog by segment was approximately 41%, 35% and 24% for the Civil, Building and Specialty Contractors segments, respectively.

The following table presents the Company’s backlog by business segment, reflecting changes from December 31, 2015 to March 31, 2016:



	Backlog at		New		Revenue		Backlog at
(in millions)	December 31, 2015		Awards (a)		Recognized		March 31, 2016
Civil	$	2,743.7	$	938.3	$	(335.9)	$	3,346.1
Building		2,780.4		562.0		(467.7)		2,874.7
Specialty Contractors		1,941.0		279.2		(281.8)		1,938.4
Total	$	7,465.1	$	1,779.5	$	(1,085.4)	$	8,159.2

(a)

New awards consist of the original contract price of projects added to our backlog plus or minus subsequent changes to the estimated total contract price of existing contracts.

In addition to our existing backlog, we have approximately $1.2 billion of pending contract awards consisting primarily of various building projects in California and Florida. We anticipate booking many of these pending awards into backlog over the next several quarters. We continue to track several large-scale civil and building prospects for both public and private sector customers.

The outlook remains favorable for growth over the next several years. In addition to our large volume of backlog, we expect significant new award activity based on long-term capital spending plans by various state, local and federal customers, favorable budget trends and typically bipartisan support for infrastructure and investments. For example, the recently enacted $305-billion Fixing America’s Surface Transportation (FAST) Act is expected to provide state and local agencies with federal funding for numerous highway, bridge and mass-transit projects between 2016 and 2020. In addition, several very large, long-duration civil infrastructure programs with which we are already involved are progressing, such as California’s High-Speed Rail system and the New York Metropolitan Transportation Authority’s East Side Access project. Planning and early projects are also underway related to Amtrak’s Northeast Corridor Improvements, including the Gateway Program, which will eventually bring new rail tunnels beneath the Hudson River to connect service between New Jersey and New York’s Penn Station. Finally, sustained low interest rates and capital costs are expected to drive high demand and continued spending by private and public customers on building and infrastructure projects.

For a more detailed discussion of operating performance of each business segment, corporate general and administrative expense and other items, see “Results of Segment Operations” and “Corporate, Tax and Other Matters” below.

Results of Segment Operations

The Company provides professional services to private and public customers in the fields of construction and construction management, including specialty construction services involving electrical; mechanical; heating, ventilation and air conditioning (HVAC); plumbing and pneumatically placed concrete primarily in the United States and its territories and in certain other international locations. The Company’s three principal business segments are: Civil, Building and Specialty Contractors. More information on these business segments is set forth in “Item 1. – Business” of our Annual Report on Form 10-K for the fiscal year ended December 31, 2015.

Civil Segment

Revenue and income from construction operations for the Civil segment are summarized as follows:

Revenue for the three months ended March 31, 2016 decreased 10% compared to the same period in 2015. The decrease was primarily driven by reduced activity on a platform project at Hudson Yards and a runway reconstruction project in New York, partially offset by increased activity on mass-transit projects in New York and California.

Table of Contents

Income from construction operations increased 10% for the three months ended March 31, 2016 compared to the same period in 2015, primarily due to the above-mentioned increased activity on mass-transit projects in New York and California.

Operating margin was 10.0% for the three months ended March 31, 2016, compared to 8.2% for the three months ended March 31, 2015. The margin increase was due to favorable performance on certain mass-transit projects in New York and California.

New awards in the Civil segment totaled $938 million for three months ended March 31, 2016 compared to $223 million for the three months ended March 31, 2015. New awards in the first quarter of 2016 included a $663 million mass-transit project in New York as well as the company’s share of more than $150 million of additional contract scope for a mass-transit project in California. New awards for the first quarter of 2015 included a $58 million highway improvement project in Pennsylvania and a $56 million tunnel project in New York.

Backlog for the Civil segment was $3.3 billion as of March 31, 2016, consistent with $3.4 billion as of March 31, 2015. The segment continues to experience strong demand reflected in a large pipeline of prospective projects and supported by favorable budget trends, agencies’ long-term spending plans and the recently enacted five-year, $305-billion FAST Act. In particular, there are a number of large prospective civil projects expected to be bid in 2016, with subsequent awards anticipated in the second half of the year or early 2017. The Civil segment is well positioned to capture its share of these prospective projects, but faces continued strong competition from various other firms, including occasional aggressive bids from foreign competitors.

Building Segment

Revenue and income from construction operations for the Building segment are as follows:

Revenue for the three months ended March 31, 2016 increased 17% compared to the same period in 2015. The growth was primarily driven by increased activity on certain commercial office, technology, government, hospitality and gaming, and retail building projects in California. The growth was partially offset by reduced activity on a hospitality and gaming project in Mississippi, an office building project in New York and a courthouse project in Florida, all of which are either completed or nearly completed.

Income from construction operations increased substantially for the three months ended March 31, 2016 compared to the same period in 2015. The increase was primarily due to the increased activity discussed above. In addition, our first quarter 2015 results included an unfavorable adjustment on an office building project in New York.

Operating margin was 2.7% for three months ended March 31, 2016 compared to (0.6)% for the three months ended March 31, 2015. The margin increase was primarily due to the reasons discussed above regarding changes in revenue and income from construction operations.

New awards in the Building segment totaled $562 million for the three months ended March 31, 2016 compared to $466 million for the three months ended March 31, 2015. New awards in the first quarter of 2016 included a $285 million hospitality and gaming project in California. New awards in the first quarter of 2015 included a $239 million hospitality building project and a $117 million mixed-use building project, both in Pennsylvania.

Backlog for the Building segment was $2.9 billion as of March 31, 2016 compared to $2.3 billion as of March 31, 2015. The strong growth in the segment’s backlog was driven by commercial office and hospitality and gaming projects awarded since the second quarter of 2015. Building segment backlog is expected to continue to grow based on a large volume of pending awards for projects primarily in California and Florida, a favorable end-market environment and a large pipeline of prospective projects. The Company anticipates that strong demand for building projects will continue as a result of customer spending supported by sustained low interest rates. The Building segment is well positioned to capture its share of prospective projects based on its strong customer relationships and a long-term reputation for excellence in delivering high-quality projects on time and within budget.

Table of Contents

Specialty Contractors Segment

Revenue and income from construction operations for the Specialty Contractors segment are:

Revenue for the three months ended March 31, 2016 decreased a modest 4% compared to the same period in 2015.

Income from construction operations decreased 11% for the three months ended March 31, 2016 compared to the same period in 2015. The decrease was primarily due to decreased activity on various mechanical projects in New York, partially offset by net favorable adjustments totaling $3.0 million for various electrical projects in New York. Included in the net favorable adjustments were material adjustments related to two electrical subcontract projects: a favorable adjustment of $14.0 million resulting from the maturation of ongoing negotiations for a completed project and an unfavorable adjustment of $13.8 million as a result of change-order negotiations and project closeout costs.

Operating margin was 3.3% for the three months ended March 31, 2016 compared to 3.6% for the three months ended March 31, 2015. The margin decrease was primarily due to the reduced activity on various mechanical projects in New York.

New awards in the Specialty Contractors segment totaled $279 million for the three months ended March 31, 2016 compared to $334 million for the three months ended March 31, 2015. New awards in the first quarter of 2016 included an $86 million electrical subcontract for a mass-transit project in New York and a $32 million mechanical subcontract for a health care project, also in New York. New awards in the first quarter of 2015 included a $90 million electrical subcontract for a mass-transit project in New York.

Backlog for the Specialty Contractors segment was $1.9 billion as of March 31, 2016 compared to $2.1 billion as of March 31, 2015. The Specialty Contractors segment has a significant pipeline of prospective projects, with demand for its services supported by strong continued spending on civil and building projects. The segment is well positioned to capture its share of prospective projects based on the size and scale of our business units that primarily operate in New York, Texas, Florida and California and the strong reputation held by these business units for high-quality work on large, complex projects.

Corporate, Tax and Other Matters

Corporate General and Administrative Expenses

Corporate general and administrative expenses were $15.4 million during the three months ended March 31, 2016 compared to $18.8 million during the three months ended March 31, 2015. The lower corporate general and administrative expenses in the first quarter of 2016 were due principally to reduced performance-based incentive compensation expense.

Other Income (Expense), Interest Expense and Provision for Income Taxes



	Three Months Ended March 31,
(in millions)	2016		2015
Other income (expense), net	$	0.7	$	(0.8)
Interest expense		(14.1)		(11.1)
Provision for income taxes		(11.3)		(3.1)

Other income (expense), net improved by $1.5 million for the three months ended March 31, 2016 compared to the same period in 2015. The improvement was due to a decrease in contingent earn-out liabilities related to past business acquisitions.

Interest expense increased $3.0 million for the three months ended March 31, 2016 compared to the same period in 2015. The increase is primarily due to a 1.1% increase in the Company’s average borrowing rate in the first quarter of 2016 and the write off of deferred debt issuance costs associated with the amendment of the Company’s Credit Facility, which were partially offset by a reduction in the Company’s average borrowings of $67.5 million.

The effective income tax rate was 42.4% for the three months ended March 31, 2016 compared to 37.5% for the same period in 2015. The effective tax rate for the first quarter of 2016 was unfavorably impacted by various discrete items, including certain state tax rate changes on deferred taxes. The effective tax rate in the first quarter of 2015 was favorably impacted by adjustments related to prior year tax positions.

Table of Contents

Liquidity and Capital Resources

Liquidity is provided by available cash and cash equivalents, cash generated from operations, credit facilities and access to capital markets. We have a $300 million revolving credit facility, which may be used for revolving loans, letters of credit and/or general purposes. We believe that for at least the next 12 months, cash generated from operations, along with our unused credit capacity of $116.3 million and cash position, is sufficient to support operating requirements.

Cash and Working Capital

Cash and cash equivalents were $90.6 million as of March 31, 2016 compared to $75.5 million as of December 31, 2015, with balances including cash held by us and available for general corporate purposes of $32.9 million and $18.4 million, respectively, and our proportionate share of cash held by joint ventures, available only for joint venture-related uses including distributions to joint venture partners, of $57.7 million and $57.0 million, respectively. In addition, our restricted cash, held primarily to secure insurance-related contingent obligations, was $49.2 million as of March 31, 2016 compared to $45.9 million as of December 31, 2015.

A summary of cash flows for the three months ended March 31, 2016 and 2015 is set forth below:



	Three Months Ended March 31,
(in millions)		2016		2015
Cash flows from:
Operating activities	$	15.9	$	(2.3)
Investing activities		(7.2)		(4.6)
Financing activities		6.4		17.3
Net increase in cash		15.1		10.4
Cash at beginning of year		75.5		135.5
Cash at end of period	$	90.6	$	145.9

During the three months ended March 31, 2016, we generated $15.9 million in cash from operating activities, which was primarily generated through earnings sources, somewhat offset by the change in working capital. In the first quarter of 2015, we received funds related to the full and final settlements on the CityCenter matter and used the proceeds to make substantial payments to subcontractors and other vendors. This activity, along with significant funding of working capital for several of our larger civil and building projects, resulted in the use of $2.3 million of cash from operating activities for the first quarter of 2015.

During the first three months of 2016, we used $7.2 million in cash from investing activities, due primarily to the acquisition of property and equipment, as compared to the use of cash of $4.6 million from investing activities in the same period of 2015.

For the first quarter of 2016, net cash provided by financing activities was $6.4 million, which was primarily due to increased net borrowings of $12.3 million, partially offset by $5.9 million in debt issuance costs associated with the restructuring of our Credit Facility in the first quarter of 2016. Net cash provided by financing activities for the comparable quarter of 2015 was $17.3 million, which was due to increased net borrowings under our Credit Facility offset by cash used for scheduled debt payments.

At March 31, 2016, we had working capital of $1.2 billion, and a ratio of current assets to current liabilities of 1.76 and a ratio of debt to equity of 0.57 compared to working capital of $1.2 billion, and a ratio of current assets to current liabilities of 1.79 and a ratio of debt to equity of 0.58 at December 31, 2015.

Long-Term Debt

We had $183.5 million of outstanding borrowings under our Revolver as of March 31, 2016 and $158.0 million of outstanding borrowings under our Revolver as of December 31, 2015. The change was primarily due to the timing of certain collections from clients that were received just after the 2016 first quarter cutoff. The Revolving Credit Facility balance reported on the Condensed Consolidated Balance Sheets as of March 31, 2016 and December 31, 2015 includes unamortized debt issuance cost of $4.8 million and $2.2 million. We utilized the Revolver for letters of credit in the amount of $0.2 million as of March 31, 2016 and December 31, 2015. Accordingly, as of March 31, 2016, we had $116.3 million of additional capacity under the Revolver.

On February 26, 2016, we entered into Waiver and Amendment No. 1 (the “Amendment”) to the Original Facility (collectively, the “Credit Facility”) with Bank of America, N.A., as Administrative Agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders. As a result of the Amendment, both the Revolver and the Term Loan will now mature on May 1, 2018, and beginning in the fourth quarter of 2016, the Company will be required to make quarterly principal payments, in addition to the scheduled amortization payments of the Original Facility, towards the Term Loan balloon payment based on a percentage of certain forecasted cash collections for the prior quarter.

Table of Contents

Borrowings under the Credit Facility bear interest based on an applicable margin added to either Bank of America’s prime lending rate or the London Interbank Offered Rate (“LIBOR”). Under the terms of the Amendment, for so long as the Company’s consolidated leverage ratio is greater than 3.5:1.0, it will not be permitted to make LIBOR-based borrowings under the Revolver and will be subject to an increased interest rate on borrowings. The interest rate will be 100 to 200 basis points higher than the highest pricing tier under the Original Facility depending on the Company’s consolidated leverage ratio. The Company also will be subject to increased commitment fees at these higher leverage ratio levels. The Amendment removes the accordion feature of the Original Facility, which would have allowed for additional borrowings of up to $300 million subject to lender approval.

The Amendment provides for the exclusion of the impact of the $23.9 million non-cash, pre-tax charge from the adverse ruling on the Brightwater litigation matter from both the calculation of the Company’s consolidated leverage ratio and consolidated fixed charge coverage ratio. In addition, the Amendment modified several of the covenants in the Original Facility, including the Company’s maximum allowable consolidated leverage ratio to be at 4.25:1.00 in the first quarter of 2016, stepping down to 4.00:1.00 in the second and third quarters of 2016 and then returning to the Original Facility’s range of 3.25:1.00 to 3.00:1.00 beginning with the fourth quarter of 2016. The Amendment adds covenants regarding the Company’s liquidity, including a cap on the cash balance in the Company’s bank account and a weekly minimum liquidity requirement (based on specified available cash balances and availability under the Revolver). Lastly, the Amendment requires the Company to achieve certain quarterly cash collection milestones and increases the lenders’ collateral package.

We are in compliance with all of the covenants under our Credit Facility as of March 31, 2016. The table below presents our actual and required consolidated fixed charge coverage ratio and consolidated leverage ratio under the Credit Facility for the period, which are calculated on a 12-month rolling basis:



	For the Three Months Ended March 31, 2016
	Actual	Required
Fixed charge coverage ratio	1.58 : 1.00	> or = 1.25 : 1.00
Leverage ratio	3.85 : 1.00	< or = 4.25 : 1.00

There has been no significant change in our contractual obligations from that described in our Annual Report on Form 10-K for the fiscal year ended December 31, 2015, filed with the Securities and Exchange Commission on February 29, 2016.

Off-Balance Sheet Arrangements

As of March 31, 2016, we do not have any off-balance sheet financing or other arrangements with unconsolidated entities, such as entities often referred to as structured finance or special purpose entities which are often established for the purpose of facilitating off-balance sheet arrangements or other contractually narrow or limited purposes. Accordingly, we are not exposed to any financing, liquidity, market or credit risk that could arise from such arrangements.

Critical Accounting Policies

Our significant accounting policies are described in Note 1. Description of Business and Summary of Significant Accounting Policies of the Notes to Consolidated Financial Statements in Part IV, Item 15. Exhibits and Financial Statement Schedules, included in our Annual Report on Form 10-K for the fiscal year ended December 31, 2015. Our critical accounting policies are also identified and discussed in Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations of our Annual Report on Form 10-K for the fiscal year ended December 31, 2015.

Recently Issued Accounting Pronouncements

See Note 2 of the Notes to Condensed Consolidated Financial Statements.

Item 3. Quantitative and Qualitative Disclosures About Market Risk

There has been no material change in our exposure to market risk from that described in Item 7A of our Annual Report on Form 10-K for the year ended December 31, 2015, filed with the Securities and Exchange Commission on February 29, 2016.

Item 4. Controls and Procedures

Disclosure Controls and Procedures

An evaluation of the effectiveness of the design and operation of our disclosure controls and procedures as defined by Rule 13a-15(e) under the Securities Exchange Act of 1934, as amended (“Exchange Act”), as of the end of the period covered by this Quarterly Report on Form 10-Q was made under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer. Based upon that evaluation, the Chief Executive Officer and Chief Financial Officer concluded

Table of Contents

that the Company’s disclosure controls and procedures (a) were effective to ensure that information we are required to disclose in reports that we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in Securities and Exchange Commission rules and forms and (b) include, without limitation, controls and procedures designed to ensure that information required to be disclosed by us in reports filed or submitted under the Exchange Act is accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosure.

Changes in Internal Controls Over Financial Reporting

There were no changes in our internal control over financial reporting during the period covered by this report that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

PART II. – OTHER INFORMATION

Item 1. Legal Proceedings

From time to time in the ordinary course of business, we are subject to claims, asserted or unasserted, or named as a party to lawsuits or investigations. Litigation can be expensive and disruptive to normal business operations. Moreover, the results of legal proceedings cannot be predicted with any certainty and, in the case of more complex legal proceedings, the results are difficult to predict at all. We disclosed information about certain of our legal proceedings in Part I, Item 3 of our Annual Report on Form 10-K for the year ended December 31, 2015. For an update to those disclosures, see Note 6 of the Notes to the Condensed Consolidated Financial Statements.

Item 1A. Risk Factors

Information regarding risk factors affecting our business is discussed in our Annual Report on Form 10-K for the year ended December 31, 2015. There have been no material changes from those risk factors during the three months ended March 31, 2016.

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds

None.

Item 3. Defaults Upon Senior Securities

None.

Item 4. Mine Safety Disclosures

Section 1503 of the Dodd-Frank Wall Street Reform and Consumer Protection Act (the “Dodd-Frank Act”) requires domestic mine operators to disclose violations and orders issued under the Federal Mine Safety and Health Act of 1977 (the “Mine Act”) by the federal Mine Safety and Health Administration. We do not act as the owner of any mines but we may act as a mining operator as defined under the Mine Act where we may be an independent contractor performing services or construction of such mine.

Information concerning mine safety violations or other regulatory matters required by Section 1503(a) of the Dodd-Frank Act and Item 104 Regulation S-K is included in Exhibit 95.

Item 5. Other Information

None.

Table of Contents

Item 6. Exhibits



Exhibit 3. Articles of Incorporation and By-laws
	3.1	Restated Articles of Organization (incorporated by reference to Exhibit 3.1 to Form10-K (File No. 001-06314) filed on March 31, 1997).
	3.2	Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on April 12, 2000).
	3.3	Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on September 11, 2008).
	3.4	Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.5 to Form 10-Q filed on August 10, 2009).
	3.5	Second Amended and Restated By-laws of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on November 24, 2009).

Exhibit 10.1		Waiver and Amendment No. 1 to the Sixth Amended and Restated Credit Agreement dated as of February 26, 2016, with Bank of America, N.A., as Administrative Agent and L/C Issuer and a syndicate of other lenders (incorporated by reference to Exhibit 10.14 to Form 10-K filed on February 29, 2016).

Exhibit 31.1		Certification of Principal Executive Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 — filed herewith.
Exhibit 31.2		Certification of Principal Financial Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 — filed herewith.
Exhibit 32.1		Certification of Principal Executive Officer Pursuant to 18 U.S.C. Section 1350, As Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 — filed herewith.
Exhibit 32.2		Certification of Principal Financial Officer Pursuant to 18 U.S.C. Section 1350, As Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 — filed herewith.

Exhibit 95		Mine Safety Disclosure — filed herewith.

Exhibit 101.INS		XBRL Instance Document.
Exhibit 101.SCH		XBRL Taxonomy Extension Schema Document.
Exhibit 101.CAL		XBRL Taxonomy Extension Calculation Linkbase Document.
Exhibit 101.LAB		XBRL Taxonomy Extension Label Linkbase Document.
Exhibit 101.PRE		XBRL Taxonomy Extension Presentation Linkbase Document.
Exhibit 101.DEF		XBRL Taxonomy Extension Definition Linkbase Document.

Table of Contents

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the Company has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.


	Tutor Perini Corporation
	(Registrant)

Dated: May 4, 2016	By:	/s/Gary G. Smalley
	Gary G. Smalley
	Executive Vice President and Chief Financial Officer